What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 31 Oct 2026, 05:00 PM. Bids are scheduled to open on 02 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹34.79 L (₹34,79,179).

How much EMD is required?

The EMD (bid security) is ₹34.8K (₹34,792). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Contractors must have a valid Civil license of requisite class ("B", "C", or "D" as per package) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD; Contractors must possess a valid H.T. License issued by ELBO, with validity of both licenses for at least 1 month from the tender opening date.

What work experience is required?

As extracted from the DTCN: Contractors must have satisfactorily completed (not less than 80% of original contract value) as prime contractor at least one similar work of not less than 40% of the proposed contract value in the last 5 years; Drilling contractors/Rig owners in joint ventures must have a minimum of 3 years of experience in successful drilling works.

What is the completion period?

The period of work is 90 days, and bids must remain valid for 90 days.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI Southern Circle Berhampur, LI Division Paralakhemundi; the tender inviting authority is the Executive Engineer, L.I.Division, Paralakhemundi.

What documents are required to submit a bid?

The DTCN lists 13 documents, including Online payment transaction receipts for tender paper cost and EMD, Valid Registration Certificate (Civil License), Valid Electrical (H.T.) License issued by ELBO, Valid GSTIN Certificate, Valid PAN Card, No Relation Certificate, and 7 more.

OtherClosed

Installation and Energisation of Latigan_I RL under Rayagada Block of Gajapati District

Executive Engineer, L.I.Division, Paralakhemundi, Gajapati Orissa Lift Irrigation CorporationLI Division Paralakhemundi

Tender ID 2026_OLIC_143939_25Ref 10/2026-27

Estimated value: ₹34.79 L
EMD: ₹34.8K; Exemption available
Tender fee: ₹7.1K
Work period: 90 days

Bid submission

Closed

Closed on 31 Oct 2026, 05:00 PM

Bid submission for this tender has closed. Browse closed tenders in the archive →

About this tender

Orissa Lift Irrigation Corporation has invited bids for “Installation and Energisation of Latigan_I RL under Rayagada Block of Gajapati District” in Executive Engineer, L.I.Division, Paralakhemundi, Gajapati district, Odisha. The estimated tender value is ₹34.79 lakh and the completion period is 90 days. Bids must be submitted by 31 Oct 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Not available: Bid submission has closed
Done: BOQ available · 65 items
Done: DTCN analysed · 34 requirements extracted
Done: 13 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published21 Oct 2026, 11:00 AM
Document downloadUntil 31 Oct 2026
Submission deadline31 Oct 2026, 05:00 PM
Bid opening02 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed34 requirements extracted13 documents identifiedExtracted from the official tender document

This tender is for the installation and energization of 58 new River Lift and Tube Well Lift Irrigation Projects under the BKVY-RIDF scheme in Gajapati District, Odisha. The projects are spread across Gosani, Kashinagar, Rayagada, Gumma, and R.Udayagiri Blocks, with estimated costs ranging from Rs. 17.65 Lakhs to Rs. 35.27 Lakhs per package. Contractors registered with the State Government or equivalent Central Government bodies are eligible to bid, provided they meet the specific class and licensing requirements for each package.

Eligibility

8 items

Contractors must have a valid Civil license of requisite class ("B", "C", or "D" as per package) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD.
Contractors must possess a valid H.T. License issued by ELBO, with validity of both licenses for at least 1 month from the tender opening date.
Joint ventures are permitted: if a contractor has only a Civil or Electrical License, they must form a registered joint venture with a contractor holding the other license.

Show 5 more

For Tube Well projects, bidders without a DTH/Mud Rotary Rig must submit a registered joint venture agreement with rig owners/contractors.
Joint Venture Agreements must be registered at the Sub-Register/District Registration Office as per the Registration Act 1908, with an agreement period of not less than 18 months.
Bidders must have a valid GST Registration certificate and PAN issued by the I.T. Department.
Bidders with unsatisfactory past progress or declared as defaulter contractors are not eligible.
A drilling contractor/owner of Rig and electrical contractors cannot make joint venture agreements with more than one Civil contractor in a single package.

Source: Original DTCNView source document

Experience

2 items

Contractors must have satisfactorily completed (not less than 80% of original contract value) as prime contractor at least one similar work of not less than 40% of the proposed contract value in the last 5 years.
Drilling contractors/Rig owners in joint ventures must have a minimum of 3 years of experience in successful drilling works.

Source: Original DTCNView source document

Financial

5 items

Bid Security (EMD) is 1% of the estimated cost, to be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD/ISD will be forfeited.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days of the letter of intent.

Show 2 more

Additional Performance Security (APS) will be taken on an incremental basis for low bid prices as per Works Department O.M. No- 07764600022025-17941/W Dated 08.10.2026.
GST, Income Tax, and 1% Labour Cess will be deducted from the contractor's bill.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

11 items

For Tube Well projects, bidders/contractors who do not own a DTH/Mud Rotary Rig must submit a joint venture agreement with Rig owners/Contractors having ownership, executed in the court of the First-Class Magistrate/Executive Magistrate.
Ownership documents of the Rig owner, including RC Book, GST registration, PAN, Fitness certificate, Permit, Insurance, and Pollution Certificate, must be submitted.
The work involves installation and energization of River Lift & Tube Well Lift Irrigation Projects, including supply of materials and labor.

Show 8 more

Contractors must erect HT, LT lines, commission Sub-Stations with all required materials, and hand over to TPSODL Electrical Division, Paralakhemundi after inspection by the Electrical Inspector.
Power supply work must adhere to REC specifications and sanctioned estimates from TPSODL, Electrical Division, Paralakhemundi.
The project must be handed over to the concerned Pani Panchayat after completion of all works and a successful trial run.
The contractor must arrange for inspection by the Electrical Inspector and obtain formal approval for energization of the sub-station, submitting a copy to the Executive Engineer.
The contractor must supply all materials, equipment, tools, and plants, ensuring they conform to relevant BIS/REC specifications.
HDPE pipes must be procured from valid EPM rate contract holders within Odisha, with pre and post-delivery inspection by CIPET, Odisha.
The contractor must arrange for testing of transformers by an approved authority before commissioning, and submit the test report and manufacturer's certificate.
The contractor must liaise with TPSODL, Electrical Division, Paralakhemundi for agreement execution, shut down, connection, charging of S/S, and handing over.

Source: Original DTCNView source document

Contract conditions

8 items

The period of completion for all projects is 90 days from the date of issue of the work order.
The bids will remain open for acceptance for a period of 365 days from the last date of receipt of bids.
Not more than 7 packages shall ordinarily be awarded to a single contractor; the authority reserves the right to reject excess packages.

Show 5 more

The successful tenderer must execute agreements with the Executive Engineer, L.I. Division, Paralakhemundi within 7 days from the date of issue of the letter of intent.
The contractor must quote the Percentage Rate excess or less up to two digits only after the decimal point.
The contractor must furnish a guarantee that all work items are free from defects for not less than 18 months from the date of handing over the project.
Payment to the contractor will be made on a "First & Final bill" basis after successful trial and handing over of the project.
Compensation for delay will be ½ percent on the estimated cost for every day the work remains uncompleted, up to a maximum of 10% of the estimated cost.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

65 priced items · ₹34.23 L (₹34,22,644)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply56%₹19.28 L
Electrical16%₹5.55 L
Earthwork & excavation7%₹2.48 L
Concrete & RCC4%₹1.32 L
Reinforcement steel2%₹74.4K
Masonry2%₹69.1K

Largest items

By amount

Cost, Supplying of ISI marked High Density Polythelene (HDPE) Pipes for water supply as per IS 4984/2016 in t…Item 46 · 1,326 M₹7.20 L
Fitting of 160 mm outer dia High Density Polythylene Pipes of specified material grade pressure rating by but…Item 21 · 1,326 M₹4.73 L
Construction and erection of 11 /0.4 KV, 63 KVA Double Pole mounted Substation with Boundary Wall (Masonary),…Item 65 · 1 NO₹4.43 L
Cost, Supplying of ISI marked High Density Polythelene (HDPE) Pipes for water supply as per IS 4984/2016 in t…Item 47 · 450 M₹3.78 L
Fitting of 200 mm outer dia High Density Polythylene Pipes of specified material grade pressure rating by but…Item 20 · 450 M₹2.18 L

Tender details

Tender reference: 10/2026-27
Tender ID: 2026_OLIC_143939_25
District: Gajapati
Location: Executive Engineer, L.I.Division, Paralakhemundi
Tender type: Open Tender
Tender category: Works
Period of work: 90 days

Show all 9 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 761200

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI Southern Circle Berhampur
Office
LI Division Paralakhemundi
Inviting authority
Executive Engineer, L.I.Division, Paralakhemundi

All Orissa Lift Irrigation Corporation tenders in Gajapati →

Costs

Estimated value: ₹34,79,179; ₹34.79 lakh
EMD / bid security: ₹34,792; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (5)

Bid Security (EMD) is 1% of the estimated cost, to be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD/ISD will be forfeited.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days of the letter of intent.
Additional Performance Security (APS) will be taken on an incremental basis for low bid prices as per Works Department O.M. No- 07764600022025-17941/W Dated 08.10.2026.
GST, Income Tax, and 1% Labour Cess will be deducted from the contractor's bill.

Source: Original DTCN

Frequently asked questions

Installation and Energisation of Latigan_I RL under Rayagada Block of Gajapati District

Tender ID 2026_OLIC_143939_25Ref 10/2026-27

Estimated value

₹34.79 L

EMD

₹34.8K

Exemption available

Tender fee

₹7.1K

Work period

90 days

Bid submission

Closed

Closed on 31 Oct 2026, 05:00 PM

About this tender

Eligibility & bid requirements

DTCN analysed34 requirements extracted13 documents identifiedExtracted from the official tender document

Eligibility

8 items

Contractors must have a valid Civil license of requisite class ("B", "C", or "D" as per package) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD.
Contractors must possess a valid H.T. License issued by ELBO, with validity of both licenses for at least 1 month from the tender opening date.
Joint ventures are permitted: if a contractor has only a Civil or Electrical License, they must form a registered joint venture with a contractor holding the other license.

Show 5 more

For Tube Well projects, bidders without a DTH/Mud Rotary Rig must submit a registered joint venture agreement with rig owners/contractors.
Joint Venture Agreements must be registered at the Sub-Register/District Registration Office as per the Registration Act 1908, with an agreement period of not less than 18 months.
Bidders must have a valid GST Registration certificate and PAN issued by the I.T. Department.
Bidders with unsatisfactory past progress or declared as defaulter contractors are not eligible.
A drilling contractor/owner of Rig and electrical contractors cannot make joint venture agreements with more than one Civil contractor in a single package.

Source: Original DTCNView source document

Experience

2 items

Contractors must have satisfactorily completed (not less than 80% of original contract value) as prime contractor at least one similar work of not less than 40% of the proposed contract value in the last 5 years.
Drilling contractors/Rig owners in joint ventures must have a minimum of 3 years of experience in successful drilling works.

Source: Original DTCNView source document

Financial

5 items

Bid Security (EMD) is 1% of the estimated cost, to be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD/ISD will be forfeited.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days of the letter of intent.

Show 2 more

Additional Performance Security (APS) will be taken on an incremental basis for low bid prices as per Works Department O.M. No- 07764600022025-17941/W Dated 08.10.2026.
GST, Income Tax, and 1% Labour Cess will be deducted from the contractor's bill.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

11 items

For Tube Well projects, bidders/contractors who do not own a DTH/Mud Rotary Rig must submit a joint venture agreement with Rig owners/Contractors having ownership, executed in the court of the First-Class Magistrate/Executive Magistrate.
Ownership documents of the Rig owner, including RC Book, GST registration, PAN, Fitness certificate, Permit, Insurance, and Pollution Certificate, must be submitted.
The work involves installation and energization of River Lift & Tube Well Lift Irrigation Projects, including supply of materials and labor.

Show 8 more

Contractors must erect HT, LT lines, commission Sub-Stations with all required materials, and hand over to TPSODL Electrical Division, Paralakhemundi after inspection by the Electrical Inspector.
Power supply work must adhere to REC specifications and sanctioned estimates from TPSODL, Electrical Division, Paralakhemundi.
The project must be handed over to the concerned Pani Panchayat after completion of all works and a successful trial run.
The contractor must arrange for inspection by the Electrical Inspector and obtain formal approval for energization of the sub-station, submitting a copy to the Executive Engineer.
The contractor must supply all materials, equipment, tools, and plants, ensuring they conform to relevant BIS/REC specifications.
HDPE pipes must be procured from valid EPM rate contract holders within Odisha, with pre and post-delivery inspection by CIPET, Odisha.
The contractor must arrange for testing of transformers by an approved authority before commissioning, and submit the test report and manufacturer's certificate.
The contractor must liaise with TPSODL, Electrical Division, Paralakhemundi for agreement execution, shut down, connection, charging of S/S, and handing over.

Source: Original DTCNView source document

Contract conditions

8 items

The period of completion for all projects is 90 days from the date of issue of the work order.
The bids will remain open for acceptance for a period of 365 days from the last date of receipt of bids.
Not more than 7 packages shall ordinarily be awarded to a single contractor; the authority reserves the right to reject excess packages.

Show 5 more

The successful tenderer must execute agreements with the Executive Engineer, L.I. Division, Paralakhemundi within 7 days from the date of issue of the letter of intent.
The contractor must quote the Percentage Rate excess or less up to two digits only after the decimal point.
The contractor must furnish a guarantee that all work items are free from defects for not less than 18 months from the date of handing over the project.
Payment to the contractor will be made on a "First & Final bill" basis after successful trial and handing over of the project.
Compensation for delay will be ½ percent on the estimated cost for every day the work remains uncompleted, up to a maximum of 10% of the estimated cost.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹34,79,179

₹34.79 lakh

EMD / bid security

₹34,792

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (5)

Bid Security (EMD) is 1% of the estimated cost, to be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD/ISD will be forfeited.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days of the letter of intent.
Additional Performance Security (APS) will be taken on an incremental basis for low bid prices as per Works Department O.M. No- 07764600022025-17941/W Dated 08.10.2026.
GST, Income Tax, and 1% Labour Cess will be deducted from the contractor's bill.

Source: Original DTCN

Frequently asked questions

Installation and Energisation of Latigan_I RL under Rayagada Block of Gajapati District

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

Installation and Energisation of Latigan_I RL under Rayagada Block of Gajapati District

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

What is the completion period?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

APPOINTMENT OF PROJECT MANAGEMENT CONSULTANCY(PMC) FOR IMPLEMENTATION OF MEGA LIFT PROJECTS IN CLUSTER No. XXXI and XXXV

APPOINTMENT OF THIRD PARTY INSPECTION AGENCY (TPIA) FOR IMPLEMENTATION OF MEGA LIFT PROJECTS IN CLUSTER No.XXXIV and XXXV

Construction of distribution system of Nuagaon Barrage Project through UGPL(Pressure Flow) system for CCA of 1979Ha in Gajapati District of state of Odisha including electro-mechanical work, power connectivity, Staff quarter and including survey....

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

What is the completion period?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

APPOINTMENT OF PROJECT MANAGEMENT CONSULTANCY(PMC) FOR IMPLEMENTATION OF MEGA LIFT PROJECTS IN CLUSTER No. XXXI and XXXV

APPOINTMENT OF THIRD PARTY INSPECTION AGENCY (TPIA) FOR IMPLEMENTATION OF MEGA LIFT PROJECTS IN CLUSTER No.XXXIV and XXXV

Construction of distribution system of Nuagaon Barrage Project through UGPL(Pressure Flow) system for CCA of 1979Ha in Gajapati District of state of Odisha including electro-mechanical work, power connectivity, Staff quarter and including survey....

Helpful guides

Explore more