What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 31 Oct 2026, 05:00 PM. Bids are scheduled to open on 02 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹20.77 L (₹20,77,000).

How much EMD is required?

The EMD (bid security) is ₹20.8K (₹20,770). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Contractors must have a valid Civil license of requisite class (B, C, or D as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD; Contractors must have a valid H.T. License issued by ELBO.

What work experience is required?

As extracted from the DTCN: For Tube Well projects, bidders without a DTH/Mud rotary Rig must submit a registered joint venture agreement with Rig owners/Contractors having ownership, executed in the court of First-Class Magistrate/Executive Magistrate; The drilling contractor/Rig owner must have a minimum of 3 years of experience in successful drilling works.

What is the completion period?

The period of work is 180 days, and bids must remain valid for 365 days.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI Southern Circle Berhampur, LI Division Berhampur; the tender inviting authority is the Executive Engineer, L.I. Division, Berhampur.

What documents are required to submit a bid?

The DTCN lists 12 documents, including Online payment transaction receipts/over the counter receipts for Paper Cost and EMD, Valid Registration Certificate (Civil License B, C, or D grade as per tender), Valid Electrical (H.T.) License issued by ELBO, Valid GSTIN Certificate, Valid PAN Card, Valid Joint Venture Agreement (Registered), and 6 more.

OtherClosed

Sunarijhola-IV T/W

OdishaOrissa Lift Irrigation CorporationLI Division Berhampur

Tender ID 2026_OLIC_143574_34Ref OLIC/BRAHMAPUR/02-2026-27

Estimated value: ₹20.77 L
EMD: ₹20.8K; Exemption available
Tender fee: ₹7.1K
Work period: 180 days

Bid submission

Closed

Closed on 31 Oct 2026, 05:00 PM

Bid submission for this tender has closed. Browse closed tenders in the archive →

About this tender

Orissa Lift Irrigation Corporation has invited bids for “Sunarijhola-IV T/W” in Sunarijhola under Kabisurya Nagar Block, Odisha. The estimated tender value is ₹20.77 lakh and the completion period is 180 days. Bids must be submitted by 31 Oct 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Not available: Bid submission has closed
Done: BOQ available · 68 items
Done: DTCN analysed · 67 requirements extracted
Done: 12 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published21 Oct 2026, 11:00 AM
Document downloadUntil 31 Oct 2026
Submission deadline31 Oct 2026, 05:00 PM
Bid opening02 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed67 requirements extracted12 documents identifiedExtracted from the official tender document

The Odisha Lift Irrigation Corporation Ltd. (OLIC) invites bids for the installation and energization of 50 new Tube Well Lift Irrigation Projects across various blocks in Ganjam District. The estimated cost for each project ranges from Rs. 18.31 Lakhs to Rs. 30.15 Lakhs. Contractors registered with the State Government or equivalent central government bodies are eligible, with a mandatory completion period of 90 days per project.

Eligibility

8 items

Contractors must have a valid Civil license of requisite class (B, C, or D as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD.
Contractors must have a valid H.T. License issued by ELBO.
Both Civil and H.T. Licenses must be valid for at least 1 month from the date of tender opening.

Show 5 more

Contractors must have a valid GST Registration certificate and PAN issued by I.T. Department.
The Joint Venture Agreement must be registered at the Sub-Register/District Registration Office as per the Registration Act 1908, with an agreement period of not less than 18 months.
If a contractor has only a Civil or Electrical License, they must form a registered joint venture with another contractor.
Price preference and other benefits will be allowed for Joint Venture Contractors if both civil and electrical contractors fall under the same reserved category as per OPWD code.
Drilling contractors/Rig owners and electrical contractors cannot form a joint venture agreement with more than one civil contractor in a single package; such bids will be rejected.

Source: Original DTCNView source document

Experience

6 items

For Tube Well projects, bidders without a DTH/Mud rotary Rig must submit a registered joint venture agreement with Rig owners/Contractors having ownership, executed in the court of First-Class Magistrate/Executive Magistrate.
The drilling contractor/Rig owner must have a minimum of 3 years of experience in successful drilling works.
Experience certificate of drilling contractor must be issued by a competent authority not below the rank of Divisional Officer.

Show 3 more

Contractors must have satisfactorily completed (not less than 80% of original contract value) at least one similar work of not less than 40% of the proposed contract value at the FY of invitation of tender price level in the last 5 years.
A weightage of 10% per year will be given to the cost of satisfactorily completed works of previous years to bring them to the current price level.
Bidders awarded similar works in the past with unsatisfactory progress or declared as defaulter contractors are not eligible.

Source: Original DTCNView source document

Financial

7 items

EMD @ 1% of the estimated cost must be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD/ISD will be forfeited.
Additional Performance Security (APS) will be calculated on an incremental basis for low bid prices, as per OM No- 07764600022025-17941/W Dated 08.10.2026.

Show 4 more

APS will be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days from the date of issue of the letter of intent.
During the guarantee period, the contractor must rectify defects within 15 days; failure to do so will result in rectification by the department at the contractor's expense, deducted from security money.
Any change in the constitution of a partnership firm must be notified to the Engineer-in-Charge within fifteen days; failure to do so may result in contract rescission and forfeiture of security deposit.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

27 items

Price preference and other financial benefits will be allowed to SC/ST, Engineer, or Physically Handicapped Contractors having both Civil & Electrical Licenses in their name as per OPWD Code.
The work involves installation and energization of 50 new Tube Well Lift Irrigation Projects, including supply of materials and labor.
Contractor must erect H.T., L.T. lines, commission Sub-Stations with all required materials, and hand over to TPSODL Electrical Division, Brahmapur after inspection by Electrical Inspector.

Show 24 more

Power supply work must adhere to REC specifications and sanctioned estimates provided by TPSODL, Electrical Division, Brahmapur.
The project must be handed over to the concerned Pani Panchayat after completion and successful trial run in the presence of beneficiaries and Engineer-in-Charge.
All construction works (Pump Chamber, Fixed foundation, Distribution Tank, ARV Tank, Butterfly Valve Tank, Supporting Pillar, HDPE Pipe Line, Road Crossing, Drilling of Bore) must be executed as per enclosed specifications (Annexure-II) and Engineer-in-Charge's direction.
Materials supplied must conform to specifications in Annexure-III for Civil works and relevant latest editions of BIS/REC Construction standards.
HDPE pipes (160mm, 200mm, 250mm dia PE_80-PN_4/PN_6) must conform to IS-4985/2000, bear ISI Mark, and have pre-delivery and post-delivery test reports by CIPET, Odisha.
G.I. pipes must conform to IS-1239 (Pt 1/2004) and be ISI certified.
Pumps must be 3 Phase Mono Block squirrel cage induction and centrifugal pump sets (with bronze impeller) with 28 LPS discharge at various heads, meeting BEE specifications and energy efficiency guidelines.
Control Panel Starters must be Auto-Star delta type suitable for 10-15 HP squirrel cage induction motors, with overloaded and single phasing preventer, Volt Meter, Amper Meter & MCB.
Cables (PVC insulated, heavy duty, armored aluminum) must conform to IS-1554(Part 1)/1988 for 1100 Volts.
PVC copper wire for connections must conform to IS 694, be multi-strand 4 mm2 size, and for 1100 Volt operation.
Main switches must conform to IS-4064/Part I & II with ISI Mark, Triple pole & neutral, 440 Volt, with re-wireable fuse of 63 AMP or 100 AMP.
G.I. Fittings, C.I. Foot Valve/NR Valve/Sluice Valve, C.I. Air Release Valve, and HDPE Fittings must conform to respective IS standards and bear ISI Mark where applicable.
Electrical construction works must adhere to REC standard and specification as per TPSODL, BOED, Brahmapur sanctioned estimate.
Contractor must supply all materials for and erect 3 Phase 11 KV line as per REC specifications, with materials varying based on field situation and average span length of 45m.
Contractor must supply all materials for commissioning 1 No. 11/0.4 KV 25 KVA, 63 KVA, or 100 KVA Sub-Station as required, per REC standard and specification.
Contractor must supply all materials for erection of L.T. Line with A.B. Cable / AAA Conductor as per REC standard.
Materials for erection of 1 No. 11 KV 3 Phase line D.P. must be as per REC standard and specification.
Compound Wall of S/S (Barbed Wire Fencing) must be as per sanctioned estimate of OLIC.
Transformer to be installed must be tested by an approved authority before commissioning, and a successful test report must be enclosed with the bill of works.
Test certificate issued by the manufacturer for the transformer must be enclosed with the bill of work.
Contractor must arrange for inspection by the Electrical Inspector/Deputy Electrical Inspector/competent authority of TPSODL, Electrical Division, Brahmapur upon completion of electrical work and obtain approval for charging the Sub-Station.
Contractor must submit the original bill of procured materials to TPSODL, Electrical Division, Brahmapur for verification and approval if required.
Contractor must liaise with TPSODL, Electrical Division, Brahmapur for execution of agreement of Pani Panchayat, shut down, connection, charging of S/S, and handing over.
Contractor must complete formalities for charging S/S, including collection and submission of test reports, preparation of checklists, and liaison for installation of 3 phase sub-station energy meter.

Source: Original DTCNView source document

Contract conditions

19 items

The period of completion for all projects is 90 days from the date of issue of the work order.
The bid will remain open for acceptance for a period of 365 days from the last date of receipt of bids.
The successful tenderer must execute agreements with the Executive Engineer, L.I. Division, Brahmapur within 7 days from the date of issue of the letter of intent.

Show 16 more

The agreement should be on approved PWD Form, incorporating all terms and conditions of this bid.
The contractor must quote the Percentage Rate excess or less up to two digits only after the decimal point.
If the contractor quotes more than two digits after the decimal point, only the first two digits will be considered without rounding.
The successful lowest bidder must submit the originals of all scanned documents within 5 days from the date of bid opening for verification.
Failure to produce original documents will result in debarment for three years and blacklisting.
If more than one bidder is L1 (quoting less than or equal to estimated cost), the tender will be decided through a transparent lottery system.
Not more than 7 packages shall ordinarily be awarded to a single contractor; the authority reserves the right to reject excess packages.
The contractor must furnish a guarantee that all work items will be free from defects for a period of not less than 18 months from the date of handing over the project.
Payment to the contractor will be made on a "First & Final bill" basis after successful trial and handing over of the project.
Compensation for delay will be ½ percent of the estimated cost for every day the work remains uncompleted, up to a maximum of 10 percent of the estimated cost.
The contractor is liable to pay compensation of one-third percent on the estimated cost for every day the due quantity of work remains incomplete at various stages.
In case of bad work, the contractor is liable to pay compensation at the rate of one percent on the estimate amount for every day, not exceeding ten days, until rectification.
The contractor is responsible for all damages to persons and property arising from the work and must indemnify OLIC against all claims.
The contractor must provide all necessary fencing and lighting to protect the public from accidents.
The contractor shall bear all taxes including GST, Income Tax, Royalty, fair weather charges, and Labour cess.
The contractor shall not sublet the work without the written approval of the Executive Engineer.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

68 priced items · ₹20.39 L (₹20,39,411)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply40%₹8.23 L
Electrical25%₹5.05 L
Earthwork & excavation21%₹4.23 L
Plaster, paint & finishing9%₹1.84 L
Concrete & RCC2%₹43.4K
Masonry2%₹37.0K

Largest items

By amount

Construction erection of 11/0.416 KV, 25 KVA (BIS level-II star 2) D.P mounted Sub-Station including transfor…Item 1.53 · 1 NO₹3.67 L
Cost, Supplying of ISI marked High Density Polythelene (HDPE) Pipes for water supply as per IS 4984/2016 in t…Item 1.37 · 660 M₹3.58 L
Fitting of 160 mm outer dia High Density Polythylene Pipes of specified material grade pressure rating by but…Item 1.14 · 660 M₹2.35 L
Construction of 3 phase 3 wire 11 KV HT line as per REC standard confirming to RE Rules 1956 excluding 400 Kg…Item 1.52 · 0.35 KM₹1.78 L
Construction of outlet at TankItem 1.17 · 20 NO₹1.78 L

Tender details

Tender reference: OLIC/BRAHMAPUR/02-2026-27
Tender ID: 2026_OLIC_143574_34
Location: Sunarijhola under Kabisurya Nagar Block
Tender type: Open Tender
Tender category: Works
Period of work: 180 days

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 760006

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI Southern Circle Berhampur
Office
LI Division Berhampur
Inviting authority
Executive Engineer, L.I. Division, Berhampur

Costs

Estimated value: ₹20,77,000; ₹20.77 lakh
EMD / bid security: ₹20,770; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 365 days

Security & deductions from the DTCN (7)

EMD @ 1% of the estimated cost must be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD/ISD will be forfeited.
Additional Performance Security (APS) will be calculated on an incremental basis for low bid prices, as per OM No- 07764600022025-17941/W Dated 08.10.2026.
APS will be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days from the date of issue of the letter of intent.
During the guarantee period, the contractor must rectify defects within 15 days; failure to do so will result in rectification by the department at the contractor's expense, deducted from security money.
Any change in the constitution of a partnership firm must be notified to the Engineer-in-Charge within fifteen days; failure to do so may result in contract rescission and forfeiture of security deposit.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed67 requirements extracted12 documents identifiedExtracted from the official tender document

Eligibility

8 items

Contractors must have a valid Civil license of requisite class (B, C, or D as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD.
Contractors must have a valid H.T. License issued by ELBO.
Both Civil and H.T. Licenses must be valid for at least 1 month from the date of tender opening.

Show 5 more

Contractors must have a valid GST Registration certificate and PAN issued by I.T. Department.
The Joint Venture Agreement must be registered at the Sub-Register/District Registration Office as per the Registration Act 1908, with an agreement period of not less than 18 months.
If a contractor has only a Civil or Electrical License, they must form a registered joint venture with another contractor.
Price preference and other benefits will be allowed for Joint Venture Contractors if both civil and electrical contractors fall under the same reserved category as per OPWD code.
Drilling contractors/Rig owners and electrical contractors cannot form a joint venture agreement with more than one civil contractor in a single package; such bids will be rejected.

Source: Original DTCNView source document

Experience

6 items

For Tube Well projects, bidders without a DTH/Mud rotary Rig must submit a registered joint venture agreement with Rig owners/Contractors having ownership, executed in the court of First-Class Magistrate/Executive Magistrate.
The drilling contractor/Rig owner must have a minimum of 3 years of experience in successful drilling works.
Experience certificate of drilling contractor must be issued by a competent authority not below the rank of Divisional Officer.

Show 3 more

Contractors must have satisfactorily completed (not less than 80% of original contract value) at least one similar work of not less than 40% of the proposed contract value at the FY of invitation of tender price level in the last 5 years.
A weightage of 10% per year will be given to the cost of satisfactorily completed works of previous years to bring them to the current price level.
Bidders awarded similar works in the past with unsatisfactory progress or declared as defaulter contractors are not eligible.

Source: Original DTCNView source document

Financial

7 items

EMD @ 1% of the estimated cost must be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD/ISD will be forfeited.
Additional Performance Security (APS) will be calculated on an incremental basis for low bid prices, as per OM No- 07764600022025-17941/W Dated 08.10.2026.

Show 4 more

APS will be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days from the date of issue of the letter of intent.
During the guarantee period, the contractor must rectify defects within 15 days; failure to do so will result in rectification by the department at the contractor's expense, deducted from security money.
Any change in the constitution of a partnership firm must be notified to the Engineer-in-Charge within fifteen days; failure to do so may result in contract rescission and forfeiture of security deposit.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

27 items

Price preference and other financial benefits will be allowed to SC/ST, Engineer, or Physically Handicapped Contractors having both Civil & Electrical Licenses in their name as per OPWD Code.
The work involves installation and energization of 50 new Tube Well Lift Irrigation Projects, including supply of materials and labor.
Contractor must erect H.T., L.T. lines, commission Sub-Stations with all required materials, and hand over to TPSODL Electrical Division, Brahmapur after inspection by Electrical Inspector.

Show 24 more

Power supply work must adhere to REC specifications and sanctioned estimates provided by TPSODL, Electrical Division, Brahmapur.
The project must be handed over to the concerned Pani Panchayat after completion and successful trial run in the presence of beneficiaries and Engineer-in-Charge.
All construction works (Pump Chamber, Fixed foundation, Distribution Tank, ARV Tank, Butterfly Valve Tank, Supporting Pillar, HDPE Pipe Line, Road Crossing, Drilling of Bore) must be executed as per enclosed specifications (Annexure-II) and Engineer-in-Charge's direction.
Materials supplied must conform to specifications in Annexure-III for Civil works and relevant latest editions of BIS/REC Construction standards.
HDPE pipes (160mm, 200mm, 250mm dia PE_80-PN_4/PN_6) must conform to IS-4985/2000, bear ISI Mark, and have pre-delivery and post-delivery test reports by CIPET, Odisha.
G.I. pipes must conform to IS-1239 (Pt 1/2004) and be ISI certified.
Pumps must be 3 Phase Mono Block squirrel cage induction and centrifugal pump sets (with bronze impeller) with 28 LPS discharge at various heads, meeting BEE specifications and energy efficiency guidelines.
Control Panel Starters must be Auto-Star delta type suitable for 10-15 HP squirrel cage induction motors, with overloaded and single phasing preventer, Volt Meter, Amper Meter & MCB.
Cables (PVC insulated, heavy duty, armored aluminum) must conform to IS-1554(Part 1)/1988 for 1100 Volts.
PVC copper wire for connections must conform to IS 694, be multi-strand 4 mm2 size, and for 1100 Volt operation.
Main switches must conform to IS-4064/Part I & II with ISI Mark, Triple pole & neutral, 440 Volt, with re-wireable fuse of 63 AMP or 100 AMP.
G.I. Fittings, C.I. Foot Valve/NR Valve/Sluice Valve, C.I. Air Release Valve, and HDPE Fittings must conform to respective IS standards and bear ISI Mark where applicable.
Electrical construction works must adhere to REC standard and specification as per TPSODL, BOED, Brahmapur sanctioned estimate.
Contractor must supply all materials for and erect 3 Phase 11 KV line as per REC specifications, with materials varying based on field situation and average span length of 45m.
Contractor must supply all materials for commissioning 1 No. 11/0.4 KV 25 KVA, 63 KVA, or 100 KVA Sub-Station as required, per REC standard and specification.
Contractor must supply all materials for erection of L.T. Line with A.B. Cable / AAA Conductor as per REC standard.
Materials for erection of 1 No. 11 KV 3 Phase line D.P. must be as per REC standard and specification.
Compound Wall of S/S (Barbed Wire Fencing) must be as per sanctioned estimate of OLIC.
Transformer to be installed must be tested by an approved authority before commissioning, and a successful test report must be enclosed with the bill of works.
Test certificate issued by the manufacturer for the transformer must be enclosed with the bill of work.
Contractor must arrange for inspection by the Electrical Inspector/Deputy Electrical Inspector/competent authority of TPSODL, Electrical Division, Brahmapur upon completion of electrical work and obtain approval for charging the Sub-Station.
Contractor must submit the original bill of procured materials to TPSODL, Electrical Division, Brahmapur for verification and approval if required.
Contractor must liaise with TPSODL, Electrical Division, Brahmapur for execution of agreement of Pani Panchayat, shut down, connection, charging of S/S, and handing over.
Contractor must complete formalities for charging S/S, including collection and submission of test reports, preparation of checklists, and liaison for installation of 3 phase sub-station energy meter.

Source: Original DTCNView source document

Contract conditions

19 items

The period of completion for all projects is 90 days from the date of issue of the work order.
The bid will remain open for acceptance for a period of 365 days from the last date of receipt of bids.
The successful tenderer must execute agreements with the Executive Engineer, L.I. Division, Brahmapur within 7 days from the date of issue of the letter of intent.

Show 16 more

The agreement should be on approved PWD Form, incorporating all terms and conditions of this bid.
The contractor must quote the Percentage Rate excess or less up to two digits only after the decimal point.
If the contractor quotes more than two digits after the decimal point, only the first two digits will be considered without rounding.
The successful lowest bidder must submit the originals of all scanned documents within 5 days from the date of bid opening for verification.
Failure to produce original documents will result in debarment for three years and blacklisting.
If more than one bidder is L1 (quoting less than or equal to estimated cost), the tender will be decided through a transparent lottery system.
Not more than 7 packages shall ordinarily be awarded to a single contractor; the authority reserves the right to reject excess packages.
The contractor must furnish a guarantee that all work items will be free from defects for a period of not less than 18 months from the date of handing over the project.
Payment to the contractor will be made on a "First & Final bill" basis after successful trial and handing over of the project.
Compensation for delay will be ½ percent of the estimated cost for every day the work remains uncompleted, up to a maximum of 10 percent of the estimated cost.
The contractor is liable to pay compensation of one-third percent on the estimated cost for every day the due quantity of work remains incomplete at various stages.
In case of bad work, the contractor is liable to pay compensation at the rate of one percent on the estimate amount for every day, not exceeding ten days, until rectification.
The contractor is responsible for all damages to persons and property arising from the work and must indemnify OLIC against all claims.
The contractor must provide all necessary fencing and lighting to protect the public from accidents.
The contractor shall bear all taxes including GST, Income Tax, Royalty, fair weather charges, and Labour cess.
The contractor shall not sublet the work without the written approval of the Executive Engineer.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹20,77,000

₹20.77 lakh

EMD / bid security

₹20,770

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 365 days

Security & deductions from the DTCN (7)

EMD @ 1% of the estimated cost must be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD/ISD will be forfeited.
Additional Performance Security (APS) will be calculated on an incremental basis for low bid prices, as per OM No- 07764600022025-17941/W Dated 08.10.2026.
APS will be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days from the date of issue of the letter of intent.
During the guarantee period, the contractor must rectify defects within 15 days; failure to do so will result in rectification by the department at the contractor's expense, deducted from security money.
Any change in the constitution of a partnership firm must be notified to the Engineer-in-Charge within fifteen days; failure to do so may result in contract rescission and forfeiture of security deposit.

Source: Original DTCN

Frequently asked questions

Sunarijhola-IV T/W

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

Sunarijhola-IV T/W

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

What is the completion period?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

What is the completion period?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more