What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 31 Oct 2026, 05:00 PM. Bids are scheduled to open on 02 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹21.30 L (₹21,30,000).

How much EMD is required?

The EMD (bid security) is ₹21.3K (₹21,300). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Contractors must have a valid Civil license of requisite class (B, C, or D as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD; Contractors must possess a valid H.T. License issued by ELBO.

What work experience is required?

As extracted from the DTCN: For Tube Well projects, bidders not owning a DTH/Mud rotary Rig must submit a registered joint venture agreement with Rig owners/Contractors having ownership, executed in the court of a First-Class Magistrate/Executive Magistrate; Rig owners/Contractors in a joint venture must have a minimum of 3 years of experience in successful drilling works.

What is the completion period?

The period of work is 180 days, and bids must remain valid for 365 days.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI Southern Circle Berhampur, LI Division Berhampur; the tender inviting authority is the Executive Engineer, L.I. Division, Berhampur.

What documents are required to submit a bid?

The DTCN lists 11 documents, including Online/Over the counter generated Paper cost & EMD challan, Valid Civil License (B, C, or D grade as per tender), Valid Electrical (H.T) License issued by ELBO, Valid GSTIN certificate, Valid PAN issued by I.T. department, Valid joint venture agreement (Registered), and 5 more.

OtherClosed

Madhurajholi T/W

OdishaOrissa Lift Irrigation CorporationLI Division Berhampur

Tender ID 2026_OLIC_143574_39Ref OLIC/BRAHMAPUR/02-2026-27

Estimated value: ₹21.30 L
EMD: ₹21.3K; Exemption available
Tender fee: ₹7.1K
Work period: 180 days

Bid submission

Closed

Closed on 31 Oct 2026, 05:00 PM

Bid submission for this tender has closed. Browse closed tenders in the archive →

About this tender

Orissa Lift Irrigation Corporation has invited bids for “Madhurajholi T/W” in Madhurajholi under Kabisurya Nagar Block, Odisha. The estimated tender value is ₹21.30 lakh and the completion period is 180 days. Bids must be submitted by 31 Oct 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Not available: Bid submission has closed
Done: BOQ available · 68 items
Done: DTCN analysed · 51 requirements extracted
Done: 11 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published21 Oct 2026, 11:00 AM
Document downloadUntil 31 Oct 2026
Submission deadline31 Oct 2026, 05:00 PM
Bid opening02 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed51 requirements extracted11 documents identifiedExtracted from the official tender document

The Odisha Lift Irrigation Corporation Ltd. (OLIC) invites bids for the installation and energization of 50 new Tube Well Lift Irrigation Projects across various blocks in Ganjam District. The estimated cost for each project ranges from Rs. 18.31 Lakhs to Rs. 30.15 Lakhs. Contractors registered with the State Government or equivalent central government bodies, holding valid Civil and HT Licenses, are eligible to bid, with a mandatory joint venture agreement for rig owners if the bidder does not own a DTH/Mud rotary rig. The completion period for all projects is 90 days from the work order issuance.

Eligibility

7 items

Contractors must have a valid Civil license of requisite class (B, C, or D as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD.
Contractors must possess a valid H.T. License issued by ELBO.
Both Civil and HT Licenses must be valid for at least 1 month from the date of tender opening.

Show 4 more

Contractors must have a valid GST Registration certificate and PAN issued by I.T. Department.
The joint venture agreement must be registered at the Sub-Register/District Registration Office as per the Registration Act 1908, with an agreement period of not less than 18 months.
Bidders with unsatisfactory past progress or declared defaulter contractors are not eligible.
Price preference and other benefits will be allowed for Joint Venture Contractors if both civil and electrical contractors fall under the same reserved category.

Source: Original DTCNView source document

Experience

3 items

For Tube Well projects, bidders not owning a DTH/Mud rotary Rig must submit a registered joint venture agreement with Rig owners/Contractors having ownership, executed in the court of a First-Class Magistrate/Executive Magistrate.
Rig owners/Contractors in a joint venture must have a minimum of 3 years of experience in successful drilling works.
Contractors must have satisfactorily completed (not less than 80% of original contract value) at least one similar work of not less than 40% of the proposed contract value at the FY of tender invitation price level in the last 5 years.

Source: Original DTCNView source document

Financial

6 items

EMD of 1% of the estimated cost must be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD will be forfeited.
Initial Security Deposit (ISD) of 1% of the accepted tendered amount must be deposited within 7 days of the letter of intent.

Show 3 more

Additional Performance Security (APS) will be calculated incrementally for bids below 10% of the estimated cost, as per OM No- 07764600022025-173/W Dated 03.01.2026 and OM No- 07764600022025-17941/W Dated 08.10.2026.
APS will be refunded upon successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The security deposit will be refunded only after the completion of the 18-month guarantee period.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

19 items

Price preference and other financial benefits will be allowed to SC/ST Contractors, Engineer Contractors, or Physically Handicapped Contractors having both Civil & Electrical Licenses in their name as per OPWD Code.
The work involves installation and energization of 50 new Tube Well Lift Irrigation Projects, including supply of materials and labor.
Contractors must erect HT, LT lines, commission Sub-Stations with all required materials, and hand over to TPSODL Electrical Division, Brahmapur after inspection by Electrical Inspector.

Show 16 more

Power supply work must adhere to REC specifications and sanctioned estimates provided by TPSODL, Electrical Division, Brahmapur.
The project must be handed over to the concerned Pani Panchayat after completion of all works and a successful trial run.
The contractor must arrange for inspection by the Electrical Inspector and obtain formal approval for energization of the sub-station, submitting a copy of approval to the Executive Engineer.
The contractor is responsible for all materials, equipment, tools, and plants, ensuring materials conform to relevant BIS/REC specifications.
HDPE pipes must conform to IS-4985/2000, be ISI marked, and have pre-delivery and post-delivery test reports from CIPET, Odisha.
GI pipes must conform to IS-1239 (Pt 1/2004) and be ISI certified.
Pumps must be 3 Phase Mono Block squirrel cage induction and centrifugal pump sets with bronze impellers, having BEE specification and energy efficiency.
Control panel starters must be Auto-Star delta type, suitable for 10-15 HP squirrel cage induction motors, with overload and single phasing preventer, Volt Meter, Amper Meter & MCB.
Cables must be PVC insulated (heavy duty) armored aluminum cable conforming to IS-1554(Part 1)/1988.
PVC copper wire for connections must conform to IS 694, be multi-strand 4 mm2 size, and rated for 1100 Volt.
Main switches must conform to IS-4064/Part I & II with ISI Mark, triple pole & neutral, 440 Volt, with re-wireable fuse of 63 AMP or 100 AMP.
GI fittings, CI Foot Valve/NR Valve/Sluice Valve, CI Air Release Valve, and HDPE fittings must conform to their respective IS standards.
Electrical construction works must follow REC standards and specifications as per TPSODL, BOED, Brahmapur sanctioned estimate.
The contractor must arrange for testing of transformers by an approved authority before commissioning and submit a successful test report and manufacturer's test certificate.
The contractor must liaise with TPSODL, Electrical Division, Brahmapur for agreement execution, shut down, connection, charging of S/S, and handing over.
The contractor must provide a guarantee that all work items are free from defects in materials and workmanship for 18 months from project handover.

Source: Original DTCNView source document

Contract conditions

16 items

The period of completion for the entire work is 90 days from the date of issue of the work order.
Bids must be submitted online in a single cover system.
The bid will be opened on 02-11-2026 at 11:00 Hrs.

Show 13 more

The bids shall remain open for acceptance for a period of 365 days from the last date of receipt of bids.
The successful lowest bidder must submit original scanned documents for verification within 5 days of bid opening.
If more than one bidder is L1, a transparent lottery system will decide the tender.
Not more than 7 packages shall ordinarily be awarded to a single contractor; the authority reserves the right to reject excess packages.
The successful tenderer must execute agreements within 7 days from the date of issue of the letter of intent.
The contractor must quote the percentage rate (excess or less) up to two digits only after the decimal point.
Payment will be made on a "First & Final bill" basis after successful trial and handover of the project.
Compensation for delay will be 0.5% of the estimated cost per day, not exceeding 10% of the estimated cost.
The contractor is liable for damages to persons and property and must take precautions to prevent accidents.
The contractor must make arrangements for water supply and curing of masonry works at their own cost.
The contractor must bear all taxes including GST, Income Tax, Royalty, fair weather charges, and Labour cess.
Unilateral stoppage of work without prior written permission will be considered a breach of contract.
The contractor must obtain a M.V. Inspection report from the Assistant Electrical Inspector concerned, with the inspection fee being reimbursable.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

68 priced items · ₹20.92 L (₹20,92,207)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply44%₹9.22 L
Electrical23%₹4.86 L
Earthwork & excavation22%₹4.56 L
Plaster, paint & finishing6%₹1.23 L
Concrete & RCC2%₹43.4K
Masonry2%₹37.0K

Largest items

By amount

Cost, Supplying of ISI marked High Density Polythelene (HDPE) Pipes for water supply as per IS 4984/2016 in t…Item 1.37 · 770 M₹4.18 L
Construction erection of 11/0.416 KV, 25 KVA (BIS level-II star 2) D.P mounted Sub-Station including transfor…Item 1.53 · 1 NO₹3.67 L
Fitting of 160 mm outer dia High Density Polythylene Pipes of specified material grade pressure rating by but…Item 1.14 · 770 M₹2.75 L
Construction of outlet at TankItem 1.17 · 21 NO₹1.87 L
Construction of 3 phase 3 wire 11 KV HT line as per REC standard confirming to RE Rules 1956 excluding 400 Kg…Item 1.52 · 0.23 KM₹1.17 L

Tender details

Tender reference: OLIC/BRAHMAPUR/02-2026-27
Tender ID: 2026_OLIC_143574_39
Location: Madhurajholi under Kabisurya Nagar Block
Tender type: Open Tender
Tender category: Works
Period of work: 180 days

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 760006

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI Southern Circle Berhampur
Office
LI Division Berhampur
Inviting authority
Executive Engineer, L.I. Division, Berhampur

Costs

Estimated value: ₹21,30,000; ₹21.30 lakh
EMD / bid security: ₹21,300; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 365 days

Security & deductions from the DTCN (6)

EMD of 1% of the estimated cost must be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD will be forfeited.
Initial Security Deposit (ISD) of 1% of the accepted tendered amount must be deposited within 7 days of the letter of intent.
Additional Performance Security (APS) will be calculated incrementally for bids below 10% of the estimated cost, as per OM No- 07764600022025-173/W Dated 03.01.2026 and OM No- 07764600022025-17941/W Dated 08.10.2026.
APS will be refunded upon successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The security deposit will be refunded only after the completion of the 18-month guarantee period.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed51 requirements extracted11 documents identifiedExtracted from the official tender document

Eligibility

7 items

Contractors must have a valid Civil license of requisite class (B, C, or D as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD.
Contractors must possess a valid H.T. License issued by ELBO.
Both Civil and HT Licenses must be valid for at least 1 month from the date of tender opening.

Show 4 more

Contractors must have a valid GST Registration certificate and PAN issued by I.T. Department.
The joint venture agreement must be registered at the Sub-Register/District Registration Office as per the Registration Act 1908, with an agreement period of not less than 18 months.
Bidders with unsatisfactory past progress or declared defaulter contractors are not eligible.
Price preference and other benefits will be allowed for Joint Venture Contractors if both civil and electrical contractors fall under the same reserved category.

Source: Original DTCNView source document

Experience

3 items

For Tube Well projects, bidders not owning a DTH/Mud rotary Rig must submit a registered joint venture agreement with Rig owners/Contractors having ownership, executed in the court of a First-Class Magistrate/Executive Magistrate.
Rig owners/Contractors in a joint venture must have a minimum of 3 years of experience in successful drilling works.
Contractors must have satisfactorily completed (not less than 80% of original contract value) at least one similar work of not less than 40% of the proposed contract value at the FY of tender invitation price level in the last 5 years.

Source: Original DTCNView source document

Financial

6 items

EMD of 1% of the estimated cost must be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD will be forfeited.
Initial Security Deposit (ISD) of 1% of the accepted tendered amount must be deposited within 7 days of the letter of intent.

Show 3 more

Additional Performance Security (APS) will be calculated incrementally for bids below 10% of the estimated cost, as per OM No- 07764600022025-173/W Dated 03.01.2026 and OM No- 07764600022025-17941/W Dated 08.10.2026.
APS will be refunded upon successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The security deposit will be refunded only after the completion of the 18-month guarantee period.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

19 items

Price preference and other financial benefits will be allowed to SC/ST Contractors, Engineer Contractors, or Physically Handicapped Contractors having both Civil & Electrical Licenses in their name as per OPWD Code.
The work involves installation and energization of 50 new Tube Well Lift Irrigation Projects, including supply of materials and labor.
Contractors must erect HT, LT lines, commission Sub-Stations with all required materials, and hand over to TPSODL Electrical Division, Brahmapur after inspection by Electrical Inspector.

Show 16 more

Power supply work must adhere to REC specifications and sanctioned estimates provided by TPSODL, Electrical Division, Brahmapur.
The project must be handed over to the concerned Pani Panchayat after completion of all works and a successful trial run.
The contractor must arrange for inspection by the Electrical Inspector and obtain formal approval for energization of the sub-station, submitting a copy of approval to the Executive Engineer.
The contractor is responsible for all materials, equipment, tools, and plants, ensuring materials conform to relevant BIS/REC specifications.
HDPE pipes must conform to IS-4985/2000, be ISI marked, and have pre-delivery and post-delivery test reports from CIPET, Odisha.
GI pipes must conform to IS-1239 (Pt 1/2004) and be ISI certified.
Pumps must be 3 Phase Mono Block squirrel cage induction and centrifugal pump sets with bronze impellers, having BEE specification and energy efficiency.
Control panel starters must be Auto-Star delta type, suitable for 10-15 HP squirrel cage induction motors, with overload and single phasing preventer, Volt Meter, Amper Meter & MCB.
Cables must be PVC insulated (heavy duty) armored aluminum cable conforming to IS-1554(Part 1)/1988.
PVC copper wire for connections must conform to IS 694, be multi-strand 4 mm2 size, and rated for 1100 Volt.
Main switches must conform to IS-4064/Part I & II with ISI Mark, triple pole & neutral, 440 Volt, with re-wireable fuse of 63 AMP or 100 AMP.
GI fittings, CI Foot Valve/NR Valve/Sluice Valve, CI Air Release Valve, and HDPE fittings must conform to their respective IS standards.
Electrical construction works must follow REC standards and specifications as per TPSODL, BOED, Brahmapur sanctioned estimate.
The contractor must arrange for testing of transformers by an approved authority before commissioning and submit a successful test report and manufacturer's test certificate.
The contractor must liaise with TPSODL, Electrical Division, Brahmapur for agreement execution, shut down, connection, charging of S/S, and handing over.
The contractor must provide a guarantee that all work items are free from defects in materials and workmanship for 18 months from project handover.

Source: Original DTCNView source document

Contract conditions

16 items

The period of completion for the entire work is 90 days from the date of issue of the work order.
Bids must be submitted online in a single cover system.
The bid will be opened on 02-11-2026 at 11:00 Hrs.

Show 13 more

The bids shall remain open for acceptance for a period of 365 days from the last date of receipt of bids.
The successful lowest bidder must submit original scanned documents for verification within 5 days of bid opening.
If more than one bidder is L1, a transparent lottery system will decide the tender.
Not more than 7 packages shall ordinarily be awarded to a single contractor; the authority reserves the right to reject excess packages.
The successful tenderer must execute agreements within 7 days from the date of issue of the letter of intent.
The contractor must quote the percentage rate (excess or less) up to two digits only after the decimal point.
Payment will be made on a "First & Final bill" basis after successful trial and handover of the project.
Compensation for delay will be 0.5% of the estimated cost per day, not exceeding 10% of the estimated cost.
The contractor is liable for damages to persons and property and must take precautions to prevent accidents.
The contractor must make arrangements for water supply and curing of masonry works at their own cost.
The contractor must bear all taxes including GST, Income Tax, Royalty, fair weather charges, and Labour cess.
Unilateral stoppage of work without prior written permission will be considered a breach of contract.
The contractor must obtain a M.V. Inspection report from the Assistant Electrical Inspector concerned, with the inspection fee being reimbursable.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹21,30,000

₹21.30 lakh

EMD / bid security

₹21,300

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 365 days

Security & deductions from the DTCN (6)

EMD of 1% of the estimated cost must be deposited online.
If a bidder withdraws or modifies their bid before the validity period, the EMD will be forfeited.
Initial Security Deposit (ISD) of 1% of the accepted tendered amount must be deposited within 7 days of the letter of intent.
Additional Performance Security (APS) will be calculated incrementally for bids below 10% of the estimated cost, as per OM No- 07764600022025-173/W Dated 03.01.2026 and OM No- 07764600022025-17941/W Dated 08.10.2026.
APS will be refunded upon successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The security deposit will be refunded only after the completion of the 18-month guarantee period.

Source: Original DTCN

Frequently asked questions

Madhurajholi T/W

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

Madhurajholi T/W

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

What is the completion period?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

What is the completion period?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more