What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 06 Nov 2026, 05:00 PM. Bids are scheduled to open on 07 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹26.30 L (₹26,30,196).

How much EMD is required?

The EMD (bid security) is ₹26.3K (₹26,302). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Reputed Contractors/Firms with valid PWD License of required class for Civil Works; Contractors must have a valid HT License issued by ELBO.

What work experience is required?

As extracted from the DTCN: For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate; Contractors having work experience of drilling works and owning a Rig are to participate in Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI,Central Circle, Cuttack, LI Division Jajpur Road; the tender inviting authority is the Executive Engineer L.I.DIvision, Jajpur Road.

What documents are required to submit a bid?

The DTCN lists 26 documents, including PWD License (Civil), HT License (Electrical), Rig Owner's Experience Certificates (for * TW projects), Rig RC Book (for * TW projects), Rig Fitness Certificate (for * TW projects), Rig Permit (for * TW projects), and 20 more.

OtherLive

PKG73

Jajpur Road, Jajpur Orissa Lift Irrigation CorporationLI Division Jajpur Road

Tender ID 2026_OLIC_144327_79Ref OLIC_02_26_27

Estimated value: ₹26.30 L
EMD: ₹26.3K; Exemption available
Tender fee: ₹7.1K
Work period: —

Closing in

3 days left

06 Nov 2026, 05:00 PM

About this tender

Orissa Lift Irrigation Corporation has invited bids for “PKG73” in Jajpur Road, Jajpur district, Odisha. The estimated tender value is ₹26.30 lakh. Bids must be submitted by 06 Nov 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Done: Tender is currently open
Done: BOQ available · 58 items
Done: DTCN analysed · 77 requirements extracted
Done: 26 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published30 Oct 2026, 02:00 PM
Document downloadUntil 06 Nov 2026
Submission deadline· 3 days left06 Nov 2026, 05:00 PM
Bid opening07 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed77 requirements extracted26 documents identifiedExtracted from the official tender document

This tender from the Odisha Lift Irrigation Corporation Limited (OLIC) invites bids for 76 packages of drilling, installation, and energization of Lift Irrigation Projects in Jajpur District. The work involves civil, electrical, and drilling components, including the erection of 11KV and LT lines, commissioning of electrical substations, and installation of pump sets. Estimated costs range from Rs. 24.60 Lakh to Rs. 29.51 Lakh per package, with a completion period of 90 days for each. Contractors must have valid PWD and HT licenses and possess a truck-mounted mud rotary rig for drilling, or enter into a joint venture with a rig owner.

Eligibility

8 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a valid HT License issued by ELBO.
Contractors registered with other State Govt./M.E.S./Railways/CPWD in equivalent rank may participate, but successful bidders must register under Odisha State PWD before signing the agreement.

Show 5 more

For joint ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
Contractors must have a truck-mounted Mud Rotary Rig for Drilling of TWs.
SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference.
P.A. holders of any SC/ST bidders must belong to the SC/ST category.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Contractors having work experience of drilling works and owning a Rig are to participate in Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years.
For TW packages, experience Rig holders must participate by making a joint venture with the required class of contractor and submit an experience certificate from an authority not less than the rank of Executive Officer of the Rig holder.

Source: Original DTCNView source document

Financial

16 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
EMD is 1% of the Estimated Cost, to be deposited online.

Show 13 more

EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
If any submitted documents are found false/fabricated/bogus, the bidder will be blacklisted and EMD forfeited.
Additional Performance Security (APS) will be obtained from the selected bidder on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per the revised Works Department O.M. No.67764600022025-17941/W, dated 08.10.26.
APS is not applicable for Turnkey Tenders.
The APS shall be treated as part of the performance security.
The APS must be submitted in the shape of NSC/Post Office Savings Bank Account/Post Office Time Deposit Account/Kishan Vikas Patra/Deposit Receipt (TDR) of a scheduled bank, properly pledged, within 7 days of the Letter of Acceptance (LOA).
Failure to submit APS will result in cancellation of the bid and forfeiture of EMD.
The successful Tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days after receipt of the Letter of Intimation, with a deposit of ISD Value of 1% in the specified forms.
No Bank Draft/D.D. is accepted for ISD.
Non-entering into agreement shall lead to forfeiture of Earnest Money.
GST will be added extra in the work order at a separate disclosure and deducted from the gross amount of the bill.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

26 items

Possession of a truck-mounted Mud Rotary Rig for Drilling of TWs.
Erection of 11 K.V. H.T. line, L.T. line, and commissioning of 11/0.4 KV substations (25 KVA to 100 KVA).
Supply of materials for 11 KV line, LT line, and substations as per Annexures B to H.

Show 23 more

Use of 55/80 mm2 A.A.A.C. conductor for 11 KV line with a span length of 0.07 km.
Use of A.B. conductor of 34 mm2 and AAA conductor of 34 mm2 for LT line with a span length of 0.03 km.
Submission of test certificate of the transformer issued by the manufacturer.
Transformers must undergo routine tests at the manufacturer's work as per IS-2026/1977 or its latest amendment.
Transformer oil must meet specified characteristics for appearance, density, viscosity, flash point, pour point, neutralization value, electric strength, dielectric dissipation factor, specific resistance, oxidation stability, and water content.
Lightening arresters must be Metal oxide gapless distribution type and meet REC Specification No. F-9.
Contractor shall employ Engineers/Technical staff as per norms of the Govt. of Odisha.
Purchase of UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied for use in works should be of ISI specification.
Bricks should be well burnt, of good quality, approved by the site Engineer, and confirm to the minimum strength as per National Building Code.
The contractor must arrange necessary tools and plants required for efficient execution of work at their own cost.
The contractor must supply necessary labour and materials for alignment, level recording, and measurement at their own cost.
All preliminary works such as GSTs, mixing platforms, etc., are to be done by the contractor at their own cost.
After work completion, all surplus materials and debris must be removed from 100 meters clear away from the site.
The contractor must provide adequate protection measures for completed works and works in progress against damages until handing over.
Dewatering from the foundation of structures, when necessary, must be done by the contractor at no extra cost.
The contractor must arrange adequate lighting arrangements for night works at their own cost.
The contractor must arrange for water supply for all works, curing of masonry works, and sanitary arrangements for labour camps at their own cost.
The contractor must ensure that the materials supplied conform to the latest ISI/CPRI specifications, or specifications made by the Executive Engineer.
The contractor must submit a work plan and monthly work progress reports for approval.
The contractor must abide by the CPWD safety code rules.
The contractor must provide footwear for labour doing cement mixing work and blacktopping of roads.
The contractor must provide shelters, first aid, drinking water, washing and bathing places, latrines, urinals, and crèche facilities for workers as per specified standards.

Source: Original DTCNView source document

Contract conditions

24 items

The completion period for each package is 90 days from the date of issue of the work order.
The validity of the offer is 180 days from the date of opening of the Financial Bids.
The cost of the Stamp paper for the agreement will be borne by the Tenderer.

Show 21 more

The work order may be placed with other participants if the approved Tenderer fails to execute the agreement or work within the stipulated time.
The authority reserves the right to increase or decrease the quantity of work or reject any or all Tenders without assigning any reason.
The contractor is responsible for payment of all royalties, local taxes (including Octroi Charges, Ferry & Tollage charges), Income Tax, and Surcharges.
No claim of idle labour/machinery/equipment will be entertained.
Conditional tenders or tenders containing extraneous conditions will not be considered.
The contract work should not be sublet to anybody without written approval; otherwise, the contract may be rescinded.
No compensation will be paid for damages caused by natural calamities during execution.
No claim for extra items or extra quantity will be entertained unless a written order is obtained and rates settled before execution.
The contractor is liable to fully indemnify the Department for any compensation under the Workmen's Compensation Act VII of 1993.
The contractor must pay fair wages to labourers, not less than the minimum wages fixed by the Government.
The contractor must submit a true statement of labour employed, working hours, wages paid, accidents, and maternity benefits by the 4th and 10th of every month.
Payment will be made after successful completion of work, testing, commissioning, handing over to the concerned Pani Panchayat, and completion of all formalities with TPNODL.
Any defect occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
No interest is chargeable for dues or additional dues.
The tenderer must sign each page of the tender paper; otherwise, it will be rejected.
Damages caused to any Govt. property/private property during pipeline work will be compensated by the contractor at their own risk and cost.
The contractor will be liable to pay compensation at the rate of 0.5% on the estimated cost for every week of delay in work completion, up to a maximum of 10% of the estimated cost.
If the compensation amount exceeds 10% of the estimated cost, the Executive Engineer may rescind the contract, and 20% of the value of left-over work will be realized as a penalty.
The defect liability period is six months from the date of final certificate of completion.
The contractor must make good any damage or imperfection appearing within six months from the date of final certificate of completion at their own expense.
If the contractor quotes abnormally low rates for some items, the Corporation may withhold the differential cost between such low rates and schedule rates from other payments until those items are completed.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

58 priced items · ₹25.83 L (₹25,82,803)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply46%₹11.92 L
Earthwork & excavation23%₹6.03 L
Electrical22%₹5.63 L
Concrete & RCC4%₹1.04 L
Masonry3%₹88.8K
Reinforcement steel1%₹17.8K

Largest items

By amount

Construction of 3 phase 11 KV HT line as per REC standard confirming to IE Rules 1956 with 300 kg 9 M long PS…Item 2.01 · 0.8 Km.₹4.17 L
Construction and erection of 11 /0.4 KV , 25 KVA Double Pole mounted Substation with 5mtrx3mtrx1.5mtr height…Item 2.02 · 1 No₹4.06 L
Cost, Supplying of ISI marked 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 for water supply as…Item 1.2 · 582 Mtr₹3.16 L
Fitting and Fixing 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 Pipe including jointing the pi…Item 1.21 · 582 Mtr₹2.00 L
From 0 mtr. to 100th metersItem 3.03 · 90 Per mtr.₹1.90 L

Tender details

Tender reference: OLIC_02_26_27
Tender ID: 2026_OLIC_144327_79
District: Jajpur
Location: Jajpur Road
Tender type: Open Tender
Tender category: Works

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 755019

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI,Central Circle, Cuttack
Office
LI Division Jajpur Road
Inviting authority
Executive Engineer L.I.DIvision, Jajpur Road

All Orissa Lift Irrigation Corporation tenders in Jajpur →

Costs

Estimated value: ₹26,30,196; ₹26.30 lakh
EMD / bid security: ₹26,302; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (14)

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
If any submitted documents are found false/fabricated/bogus, the bidder will be blacklisted and EMD forfeited.
Additional Performance Security (APS) will be obtained from the selected bidder on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per the revised Works Department O.M. No.67764600022025-17941/W, dated 08.10.26.
APS is not applicable for Turnkey Tenders.
The APS shall be treated as part of the performance security.
The APS must be submitted in the shape of NSC/Post Office Savings Bank Account/Post Office Time Deposit Account/Kishan Vikas Patra/Deposit Receipt (TDR) of a scheduled bank, properly pledged, within 7 days of the Letter of Acceptance (LOA).
Failure to submit APS will result in cancellation of the bid and forfeiture of EMD.
The successful Tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days after receipt of the Letter of Intimation, with a deposit of ISD Value of 1% in the specified forms.
No Bank Draft/D.D. is accepted for ISD.
GST will be added extra in the work order at a separate disclosure and deducted from the gross amount of the bill.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed77 requirements extracted26 documents identifiedExtracted from the official tender document

Eligibility

8 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a valid HT License issued by ELBO.
Contractors registered with other State Govt./M.E.S./Railways/CPWD in equivalent rank may participate, but successful bidders must register under Odisha State PWD before signing the agreement.

Show 5 more

For joint ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
Contractors must have a truck-mounted Mud Rotary Rig for Drilling of TWs.
SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference.
P.A. holders of any SC/ST bidders must belong to the SC/ST category.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Contractors having work experience of drilling works and owning a Rig are to participate in Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years.
For TW packages, experience Rig holders must participate by making a joint venture with the required class of contractor and submit an experience certificate from an authority not less than the rank of Executive Officer of the Rig holder.

Source: Original DTCNView source document

Financial

16 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
EMD is 1% of the Estimated Cost, to be deposited online.

Show 13 more

EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
If any submitted documents are found false/fabricated/bogus, the bidder will be blacklisted and EMD forfeited.
Additional Performance Security (APS) will be obtained from the selected bidder on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per the revised Works Department O.M. No.67764600022025-17941/W, dated 08.10.26.
APS is not applicable for Turnkey Tenders.
The APS shall be treated as part of the performance security.
The APS must be submitted in the shape of NSC/Post Office Savings Bank Account/Post Office Time Deposit Account/Kishan Vikas Patra/Deposit Receipt (TDR) of a scheduled bank, properly pledged, within 7 days of the Letter of Acceptance (LOA).
Failure to submit APS will result in cancellation of the bid and forfeiture of EMD.
The successful Tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days after receipt of the Letter of Intimation, with a deposit of ISD Value of 1% in the specified forms.
No Bank Draft/D.D. is accepted for ISD.
Non-entering into agreement shall lead to forfeiture of Earnest Money.
GST will be added extra in the work order at a separate disclosure and deducted from the gross amount of the bill.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

26 items

Possession of a truck-mounted Mud Rotary Rig for Drilling of TWs.
Erection of 11 K.V. H.T. line, L.T. line, and commissioning of 11/0.4 KV substations (25 KVA to 100 KVA).
Supply of materials for 11 KV line, LT line, and substations as per Annexures B to H.

Show 23 more

Use of 55/80 mm2 A.A.A.C. conductor for 11 KV line with a span length of 0.07 km.
Use of A.B. conductor of 34 mm2 and AAA conductor of 34 mm2 for LT line with a span length of 0.03 km.
Submission of test certificate of the transformer issued by the manufacturer.
Transformers must undergo routine tests at the manufacturer's work as per IS-2026/1977 or its latest amendment.
Transformer oil must meet specified characteristics for appearance, density, viscosity, flash point, pour point, neutralization value, electric strength, dielectric dissipation factor, specific resistance, oxidation stability, and water content.
Lightening arresters must be Metal oxide gapless distribution type and meet REC Specification No. F-9.
Contractor shall employ Engineers/Technical staff as per norms of the Govt. of Odisha.
Purchase of UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied for use in works should be of ISI specification.
Bricks should be well burnt, of good quality, approved by the site Engineer, and confirm to the minimum strength as per National Building Code.
The contractor must arrange necessary tools and plants required for efficient execution of work at their own cost.
The contractor must supply necessary labour and materials for alignment, level recording, and measurement at their own cost.
All preliminary works such as GSTs, mixing platforms, etc., are to be done by the contractor at their own cost.
After work completion, all surplus materials and debris must be removed from 100 meters clear away from the site.
The contractor must provide adequate protection measures for completed works and works in progress against damages until handing over.
Dewatering from the foundation of structures, when necessary, must be done by the contractor at no extra cost.
The contractor must arrange adequate lighting arrangements for night works at their own cost.
The contractor must arrange for water supply for all works, curing of masonry works, and sanitary arrangements for labour camps at their own cost.
The contractor must ensure that the materials supplied conform to the latest ISI/CPRI specifications, or specifications made by the Executive Engineer.
The contractor must submit a work plan and monthly work progress reports for approval.
The contractor must abide by the CPWD safety code rules.
The contractor must provide footwear for labour doing cement mixing work and blacktopping of roads.
The contractor must provide shelters, first aid, drinking water, washing and bathing places, latrines, urinals, and crèche facilities for workers as per specified standards.

Source: Original DTCNView source document

Contract conditions

24 items

The completion period for each package is 90 days from the date of issue of the work order.
The validity of the offer is 180 days from the date of opening of the Financial Bids.
The cost of the Stamp paper for the agreement will be borne by the Tenderer.

Show 21 more

The work order may be placed with other participants if the approved Tenderer fails to execute the agreement or work within the stipulated time.
The authority reserves the right to increase or decrease the quantity of work or reject any or all Tenders without assigning any reason.
The contractor is responsible for payment of all royalties, local taxes (including Octroi Charges, Ferry & Tollage charges), Income Tax, and Surcharges.
No claim of idle labour/machinery/equipment will be entertained.
Conditional tenders or tenders containing extraneous conditions will not be considered.
The contract work should not be sublet to anybody without written approval; otherwise, the contract may be rescinded.
No compensation will be paid for damages caused by natural calamities during execution.
No claim for extra items or extra quantity will be entertained unless a written order is obtained and rates settled before execution.
The contractor is liable to fully indemnify the Department for any compensation under the Workmen's Compensation Act VII of 1993.
The contractor must pay fair wages to labourers, not less than the minimum wages fixed by the Government.
The contractor must submit a true statement of labour employed, working hours, wages paid, accidents, and maternity benefits by the 4th and 10th of every month.
Payment will be made after successful completion of work, testing, commissioning, handing over to the concerned Pani Panchayat, and completion of all formalities with TPNODL.
Any defect occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
No interest is chargeable for dues or additional dues.
The tenderer must sign each page of the tender paper; otherwise, it will be rejected.
Damages caused to any Govt. property/private property during pipeline work will be compensated by the contractor at their own risk and cost.
The contractor will be liable to pay compensation at the rate of 0.5% on the estimated cost for every week of delay in work completion, up to a maximum of 10% of the estimated cost.
If the compensation amount exceeds 10% of the estimated cost, the Executive Engineer may rescind the contract, and 20% of the value of left-over work will be realized as a penalty.
The defect liability period is six months from the date of final certificate of completion.
The contractor must make good any damage or imperfection appearing within six months from the date of final certificate of completion at their own expense.
If the contractor quotes abnormally low rates for some items, the Corporation may withhold the differential cost between such low rates and schedule rates from other payments until those items are completed.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹26,30,196

₹26.30 lakh

EMD / bid security

₹26,302

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (14)

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
If any submitted documents are found false/fabricated/bogus, the bidder will be blacklisted and EMD forfeited.
Additional Performance Security (APS) will be obtained from the selected bidder on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per the revised Works Department O.M. No.67764600022025-17941/W, dated 08.10.26.
APS is not applicable for Turnkey Tenders.
The APS shall be treated as part of the performance security.
The APS must be submitted in the shape of NSC/Post Office Savings Bank Account/Post Office Time Deposit Account/Kishan Vikas Patra/Deposit Receipt (TDR) of a scheduled bank, properly pledged, within 7 days of the Letter of Acceptance (LOA).
Failure to submit APS will result in cancellation of the bid and forfeiture of EMD.
The successful Tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days after receipt of the Letter of Intimation, with a deposit of ISD Value of 1% in the specified forms.
No Bank Draft/D.D. is accepted for ISD.
GST will be added extra in the work order at a separate disclosure and deducted from the gross amount of the bill.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

Source: Original DTCN

Frequently asked questions

PKG73

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

PKG73

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more