What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 06 Nov 2026, 05:00 PM. Bids are scheduled to open on 07 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹26.26 L (₹26,25,850).

How much EMD is required?

The EMD (bid security) is ₹26.3K (₹26,259). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Reputed Contractors/Firms with valid PWD License of required class for Civil Works; Contractors must possess a truck-mounted Mud Rotary Rig for Drilling of TWs.

What work experience is required?

As extracted from the DTCN: For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate; Contractors should have executed similar type of work in the last five years.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI,Central Circle, Cuttack, LI Division Jajpur Road; the tender inviting authority is the Executive Engineer L.I.DIvision, Jajpur Road.

What documents are required to submit a bid?

The DTCN lists 17 documents, including Valid PWD License (Civil Works), Registered HT License (Electrical), Digital Signature Certificate (DSC), GST Clearance Certificate, PAN Card, Affidavit (for EMD exemption, if applicable), and 11 more.

OtherLive

PKG72

Jajpur Road, Jajpur Orissa Lift Irrigation CorporationLI Division Jajpur Road

Tender ID 2026_OLIC_144327_78Ref OLIC_02_26_27

Estimated value: ₹26.26 L
EMD: ₹26.3K; Exemption available
Tender fee: ₹7.1K
Work period: —

Closing in

3 days left

06 Nov 2026, 05:00 PM

About this tender

Orissa Lift Irrigation Corporation has invited bids for “PKG72” in Jajpur Road, Jajpur district, Odisha. The estimated tender value is ₹26.26 lakh. Bids must be submitted by 06 Nov 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Done: Tender is currently open
Done: BOQ available · 59 items
Done: DTCN analysed · 46 requirements extracted
Done: 17 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published30 Oct 2026, 02:00 PM
Document downloadUntil 06 Nov 2026
Submission deadline· 3 days left06 Nov 2026, 05:00 PM
Bid opening07 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed46 requirements extracted17 documents identifiedExtracted from the official tender document

This tender from the Odisha Lift Irrigation Corporation Ltd. invites bids for 76 packages of drilling, installation, and energization of Lift Irrigation Projects in Jajpur District on a turnkey basis. The estimated cost for each package ranges from Rs. 24.60 Lakh to Rs. 29.51 Lakh. Contractors need a valid PWD license for civil works, a truck-mounted mud rotary rig for drilling, and must handle the erection of 11KV and LT lines, electrical substation commissioning, and pump set installation.

Eligibility

10 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must possess a truck-mounted Mud Rotary Rig for Drilling of TWs.
Contractors registered with State Govt. of Odisha or equivalent grade/class registered with other State Govt./Central Govt./M.E.S./Railways or other Govt. undertakings.

Show 7 more

Must have a Registered HT License issued by ELBO.
Must be registered in the State portal and possess a compatible digital signature certificate.
For Joint Ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
Defaulter contractors are not allowed to participate.
SC/ST contractors can avail price preference if they have both Civil & Electrical Licenses (no preference for Joint Ventures).
If registered under other State Govt./M.E.s/Railways/CPWD, successful bidders must register under Odisha State PWD before signing the agreement.
PA holders of SC/ST bidders must belong to SC/ST category.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Contractors should have executed similar type of work in the last five years.
For TW packages, experienced Rig holders must participate in a joint venture with the required class of contractor and submit an experience certificate from an authority not less than the rank of Executive Officer of the RIG holder.

Source: Original DTCNView source document

Financial

9 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the 'Rounding Off of Percentage Less (ROPL)' of the accepted bid price.

Show 6 more

The APS is treated as part of the performance security and is not applicable to Turnkey Tenders.
The successful bidder must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing an ISD Value of 1% in specified instruments.
Failure to execute the agreement or furnish required Performance Security will lead to EMD forfeiture.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
1% of the gross bill amount will be deducted towards labour cess.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

12 items

Contractors must have a truck-mounted Mud Rotary Rig for drilling of TWs.
Contractors having their own plants and machineries (Rig & Ancillaries) will be given weightage.
Contractor shall employ Engineers/Technical staff as per norms of the Govt. of Odisha.

Show 9 more

For electrical works, the contractor must erect 11 KV H.T. line, L.T. line, and commission 11/0.4 KV stations (25 KVA to 100 KVA).
The size of conductor for 11 KV line is 55/80 mm2 A.A.A.C. with a span length of 0.07 km.
L.T. line materials are for A.B. conductor of 34 mm2 and AAA conductor of 34 mm2 with a span length of 0.03 km.
Transformers must undergo routine tests as per IS-2026/1977 or its latest amendment.
Transformer oil must meet specified characteristics regarding appearance, density, viscosity, flash point, neutralization value, electric strength, etc.
Lightening arresters must be Metal oxide gapless distribution type and meet REC Specification No. F-9.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied by the contractor should conform to the latest ISI/CPRI specifications.
Bricks should be well burnt, of good quality, approved by the site Engineer, and confirm to the minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

12 items

The completion period for each work package is 90 days from the date of issue of the work order.
The offer validity period is 180 days from the date of opening of Financial Bids.
Compensation for delay is 0.5% of the estimated cost per week, up to a maximum of 10% of the estimated cost.

Show 9 more

The defect liability period is 18 months after completion of works or commissioning of the project; the contractor must rectify defects within 7 days.
All taxes, cess, royalties, income tax, surcharges, and labour cess will be borne by the bidder; GST will be paid extra.
Payment will be made after successful completion of work, testing, commissioning, handing over to the concerned Pani Panchayat, and completion of all formalities with TPNODL.
No claim for idle labour/machinery/equipment will be entertained.
The contract work should not be sublet to anybody; otherwise, the contract may be rescinded.
The authority reserves the right to increase or decrease quantities of work items; no compensation will be paid for this, only time extension if necessary.
No compensation will be paid for damages due to natural calamities.
Interest is not chargeable for dues or additional dues.
The contractor must sign each page of the tender paper; otherwise, the tender will be rejected.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

59 priced items · ₹25.78 L (₹25,78,457)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply44%₹11.39 L
Electrical25%₹6.35 L
Earthwork & excavation23%₹5.88 L
Concrete & RCC4%₹97.6K
Masonry3%₹88.8K
Reinforcement steel1%₹16.8K

Largest items

By amount

Construction and erection of 11 /0.4 KV , 25 KVA Double Pole mounted Substation with 5mtrx3mtrx1.5mtr height…Item 2.02 · 1 No₹4.06 L
Construction of 3 phase 11 KV HT line as per REC standard confirming to IE Rules 1956 with 300 kg 9 M long PS…Item 2.01 · 0.7 Km.₹3.65 L
Cost, Supplying of ISI marked 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 for water supply as…Item 1.2 · 522 Mtr₹2.84 L
From 0 mtr. to 100th metersItem 3.03 · 90 Per mtr.₹1.90 L
Fitting and Fixing 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 Pipe including jointing the pi…Item 1.21 · 522 Mtr₹1.80 L

Tender details

Tender reference: OLIC_02_26_27
Tender ID: 2026_OLIC_144327_78
District: Jajpur
Location: Jajpur Road
Tender type: Open Tender
Tender category: Works

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 755019

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI,Central Circle, Cuttack
Office
LI Division Jajpur Road
Inviting authority
Executive Engineer L.I.DIvision, Jajpur Road

All Orissa Lift Irrigation Corporation tenders in Jajpur →

Costs

Estimated value: ₹26,25,850; ₹26.26 lakh
EMD / bid security: ₹26,259; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (8)

EMD is 1% of the Estimated Cost, to be deposited online.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the 'Rounding Off of Percentage Less (ROPL)' of the accepted bid price.
The APS is treated as part of the performance security and is not applicable to Turnkey Tenders.
The successful bidder must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing an ISD Value of 1% in specified instruments.
Failure to execute the agreement or furnish required Performance Security will lead to EMD forfeiture.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
1% of the gross bill amount will be deducted towards labour cess.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed46 requirements extracted17 documents identifiedExtracted from the official tender document

Eligibility

10 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must possess a truck-mounted Mud Rotary Rig for Drilling of TWs.
Contractors registered with State Govt. of Odisha or equivalent grade/class registered with other State Govt./Central Govt./M.E.S./Railways or other Govt. undertakings.

Show 7 more

Must have a Registered HT License issued by ELBO.
Must be registered in the State portal and possess a compatible digital signature certificate.
For Joint Ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
Defaulter contractors are not allowed to participate.
SC/ST contractors can avail price preference if they have both Civil & Electrical Licenses (no preference for Joint Ventures).
If registered under other State Govt./M.E.s/Railways/CPWD, successful bidders must register under Odisha State PWD before signing the agreement.
PA holders of SC/ST bidders must belong to SC/ST category.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Contractors should have executed similar type of work in the last five years.
For TW packages, experienced Rig holders must participate in a joint venture with the required class of contractor and submit an experience certificate from an authority not less than the rank of Executive Officer of the RIG holder.

Source: Original DTCNView source document

Financial

9 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the 'Rounding Off of Percentage Less (ROPL)' of the accepted bid price.

Show 6 more

The APS is treated as part of the performance security and is not applicable to Turnkey Tenders.
The successful bidder must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing an ISD Value of 1% in specified instruments.
Failure to execute the agreement or furnish required Performance Security will lead to EMD forfeiture.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
1% of the gross bill amount will be deducted towards labour cess.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

12 items

Contractors must have a truck-mounted Mud Rotary Rig for drilling of TWs.
Contractors having their own plants and machineries (Rig & Ancillaries) will be given weightage.
Contractor shall employ Engineers/Technical staff as per norms of the Govt. of Odisha.

Show 9 more

For electrical works, the contractor must erect 11 KV H.T. line, L.T. line, and commission 11/0.4 KV stations (25 KVA to 100 KVA).
The size of conductor for 11 KV line is 55/80 mm2 A.A.A.C. with a span length of 0.07 km.
L.T. line materials are for A.B. conductor of 34 mm2 and AAA conductor of 34 mm2 with a span length of 0.03 km.
Transformers must undergo routine tests as per IS-2026/1977 or its latest amendment.
Transformer oil must meet specified characteristics regarding appearance, density, viscosity, flash point, neutralization value, electric strength, etc.
Lightening arresters must be Metal oxide gapless distribution type and meet REC Specification No. F-9.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied by the contractor should conform to the latest ISI/CPRI specifications.
Bricks should be well burnt, of good quality, approved by the site Engineer, and confirm to the minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

12 items

The completion period for each work package is 90 days from the date of issue of the work order.
The offer validity period is 180 days from the date of opening of Financial Bids.
Compensation for delay is 0.5% of the estimated cost per week, up to a maximum of 10% of the estimated cost.

Show 9 more

The defect liability period is 18 months after completion of works or commissioning of the project; the contractor must rectify defects within 7 days.
All taxes, cess, royalties, income tax, surcharges, and labour cess will be borne by the bidder; GST will be paid extra.
Payment will be made after successful completion of work, testing, commissioning, handing over to the concerned Pani Panchayat, and completion of all formalities with TPNODL.
No claim for idle labour/machinery/equipment will be entertained.
The contract work should not be sublet to anybody; otherwise, the contract may be rescinded.
The authority reserves the right to increase or decrease quantities of work items; no compensation will be paid for this, only time extension if necessary.
No compensation will be paid for damages due to natural calamities.
Interest is not chargeable for dues or additional dues.
The contractor must sign each page of the tender paper; otherwise, the tender will be rejected.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹26,25,850

₹26.26 lakh

EMD / bid security

₹26,259

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (8)

EMD is 1% of the Estimated Cost, to be deposited online.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the 'Rounding Off of Percentage Less (ROPL)' of the accepted bid price.
The APS is treated as part of the performance security and is not applicable to Turnkey Tenders.
The successful bidder must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing an ISD Value of 1% in specified instruments.
Failure to execute the agreement or furnish required Performance Security will lead to EMD forfeiture.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
1% of the gross bill amount will be deducted towards labour cess.

Source: Original DTCN

Frequently asked questions

PKG72

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

PKG72

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more