What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 06 Nov 2026, 05:00 PM. Bids are scheduled to open on 07 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹26.40 L (₹26,39,667).

How much EMD is required?

The EMD (bid security) is ₹26.4K (₹26,397). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Reputed Contractors/Firms with valid PWD License of required class for Civil Works; Contractors must have a Truck mounted Mud Rotary Rig for Drilling of TWs.

What work experience is required?

As extracted from the DTCN: For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate; For TW packages, experience Rig holders must participate in Joint Venture Agreement with the required class of contractor and submit an Experience certificate from an Authority not less than the Rank of Executive Officer of the RIG holder.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI,Central Circle, Cuttack, LI Division Jajpur Road; the tender inviting authority is the Executive Engineer L.I.DIvision, Jajpur Road.

What documents are required to submit a bid?

The DTCN lists 21 documents, including PWD License, HT License, Rig Owner's Experience Certificates (for * TW projects), Rig RC Book (for * TW projects), Rig Fitness Certificate (for * TW projects), Rig Permit (for * TW projects), and 15 more.

OtherLive

PKG68

Jajpur Road, Jajpur Orissa Lift Irrigation CorporationLI Division Jajpur Road

Tender ID 2026_OLIC_144327_73Ref OLIC_02_26_27

Estimated value: ₹26.40 L
EMD: ₹26.4K; Exemption available
Tender fee: ₹7.1K
Work period: —

Closing in

3 days left

06 Nov 2026, 05:00 PM

About this tender

Orissa Lift Irrigation Corporation has invited bids for “PKG68” in Jajpur Road, Jajpur district, Odisha. The estimated tender value is ₹26.40 lakh. Bids must be submitted by 06 Nov 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Done: Tender is currently open
Done: BOQ available · 58 items
Done: DTCN analysed · 67 requirements extracted
Done: 21 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published30 Oct 2026, 12:00 PM
Document downloadUntil 06 Nov 2026
Submission deadline· 3 days left06 Nov 2026, 05:00 PM
Bid opening07 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed67 requirements extracted21 documents identifiedExtracted from the official tender document

This tender from the Odisha Lift Irrigation Corporation Limited (OLIC) invites bids for the drilling, installation, and energization of 76 Lift Irrigation Projects in Jajpur District. The projects, valued between Rs. 24.60 Lakh and Rs. 29.51 Lakh, require contractors with valid PWD and HT licenses, and experience with truck-mounted mud rotary rigs. The work is to be completed on a turnkey basis within 90 days for each project.

Eligibility

9 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a Truck mounted Mud Rotary Rig for Drilling of TWs.
Contractors must have a valid HT License issued by ELBO.

Show 6 more

Registered with the State Govt. of Odisha or equivalent grade/class registered with other State Govt./Central Govt./M.E.S./Railways or other Govt. undertakings.
For Joint Ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
SC/ST contractors with both Civil & Electrical Licenses may receive price preference.
Bidders registered under other State Govt./M.E.S./Railways/CPWD in equivalent rank may participate but must register under the state PWD before signing the agreement if successful.
The P.A holders of any SC/ST bidders should belong to the SC/ST category only.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

2 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
For TW packages, experience Rig holders must participate in Joint Venture Agreement with the required class of contractor and submit an Experience certificate from an Authority not less than the Rank of Executive Officer of the RIG holder.

Source: Original DTCNView source document

Financial

13 items

Contractors should not have been awarded a minimum of 3 works during the current financial year to avail EMD exemption (requires affidavit).
The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.

Show 10 more

EMD will be forfeited if a successful bidder fails to execute the agreement or furnish required Performance Security within the specified time.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per Works Department O.M. No.67764600022025-17941/W, Dt.08.10.26.
The APS provision is not applicable to Turnkey Tenders.
ISD Value of 1% must be deposited in the form of NSC/Post Office Savings Bank Account/Post Office Time Deposit Account/Kishan Vikas Patra/Deposit Receipt (TDR) of a scheduled bank, pledged in favor of the Executive Engineer, L.I. Division, JAJPUR ROAD.
No Bank Draft/D.D. is accepted for ISD.
Non-entering into agreement shall lead to forfeiture of Earnest Money.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.
Security deposit of 5% of the bill will be deducted and refunded 18 months after handing over and final bill payment.
If the contractor fails to rectify defects, the Department may engage another contractor and deduct costs from the security deposit.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

15 items

Possession of a Truck mounted Mud Rotary Rig for Drilling of TWs.
Erection of 11KV Line, L.T Line & Commissioning of Electrical Substation for power supply to L.I Projects.
Installation of Pump Set, Starter and its energisation.

Show 12 more

Weightage may be given to contractors having their own plants and machineries (Rig & Ancillaries).
Contractor shall employ Engineers/Tech. staff as per norms of the Govt. of Odisha.
Materials for 11 KV line: 55/80 mm2 A.A.A.C. conductor, span length 0.07 km.
Materials for L.T. line: A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, span length 0.03 km.
Sub-stations: 11/0.4 KV, 25 KVA to 100 KVA.
Test certificate of the transformer issued by the manufacturer must be submitted.
All transformers shall be subjected to routine tests as per IS-2026/1977 or its latest amendment.
Transformer oil characteristics must meet specified standards (e.g., density, viscosity, flash point, electric strength).
Lightening arrester must be Metal oxide gapless distribution type, 12 KV rated voltage, 5 KA nominal discharge current, meeting REC Specification No. F-9.
UPVC Pipe, HDPE Pipe and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied must conform to the latest ISI/CPRI specifications, or specifications made by the Executive Engineer.
Bricks must be well burnt, of good quality, approved by the site Engineer, and confirm to the minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

28 items

Bids must be submitted online only.
Last date for online bid submission is Dt. 03.11.26 up to 5:00 P.M.
Bid opening date is Dt. 04.11.26 at 11:00 A.M.

Show 25 more

Offer validity is 180 days from the date of opening of Financial Bids.
Completion period for each work is 90 days from the date of issue of work order.
Compensation for delay is 0.5% of the estimated cost per week, up to a maximum of 10% of the estimated cost.
The successful Tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation.
The cost of the Stamp paper for the agreement will be borne by the Tenderer.
The work will not be sublet without written permission from the Executive Engineer.
The authority reserves the right to increase or decrease the quantity of work items, or reject any/all tenders, or distribute works without assigning reasons.
Contractors are liable to fully indemnify the Department for any compensation under the Workmen's Compensation Act VII of 1993.
Contractors must abide by fair wages clauses and not pay less than the fair wages fixed by the Govt. to laborers.
All taxes, cess, royalties, income taxes, and surcharges (except GST) are to be borne by the bidder; GST will be paid extra.
Royalties for materials utilized will be recovered from the bill based on Govt. fixed rates.
The contractor is responsible for all preliminary works (e.g., GSTs, mixing platforms) and their dismantling and removal at their own cost.
No compensation will be paid for damage due to natural calamities.
No claim for idle labor/machinery/equipment will be entertained.
Interest is not chargeable for dues or additional dues.
The contractor must provide adequate protection measures for completed works and works in progress until handing over.
Dewatering from foundations is at the contractor's cost.
Quantities for items with quoted rates more than 25% of estimated rates cannot be varied by more than 5% without competent authority approval.
Any defect occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
Payment will be made after completion of work, handing over of electric line and substation to TPNODL, and completion of all formalities with TPNODL.
The works bill will be paid after a resolution from Pani Panchayat members confirming work completion and successful trial run.
The contractor must inform the President/Secretary and Pani Panchayat members for commissioning and trial run.
After completion, materials fitted at the project should be handed over to the President/Secretary of the Pani Panchayat.
The electrical works will be handed over to TPNODL for maintenance after completion.
The contractor must sign each page of the tender paper; unsigned tenders will be rejected.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

58 priced items · ₹25.92 L (₹25,92,274)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply51%₹13.33 L
Earthwork & excavation24%₹6.28 L
Electrical16%₹4.07 L
Concrete & RCC4%₹1.04 L
Masonry3%₹88.8K
Reinforcement steel1%₹17.8K

Largest items

By amount

Construction and erection of 11 /0.4 KV , 25 KVA Double Pole mounted Substation with 5mtrx3mtrx1.5mtr height…Item 2.02 · 1 No₹4.06 L
Cost, Supplying of ISI marked 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 for water supply as…Item 1.2 · 740 Mtr₹4.02 L
Construction of 3 phase 11 KV HT line as per REC standard confirming to IE Rules 1956 with 300 kg 9 M long PS…Item 2.01 · 0.5 Km.₹2.61 L
Fitting and Fixing 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 Pipe including jointing the pi…Item 1.21 · 740 Mtr₹2.55 L
From 0 mtr. to 100th metersItem 3.03 · 90 Per mtr.₹1.90 L

Tender details

Tender reference: OLIC_02_26_27
Tender ID: 2026_OLIC_144327_73
District: Jajpur
Location: Jajpur Road
Tender type: Open Tender
Tender category: Works

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 755019

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI,Central Circle, Cuttack
Office
LI Division Jajpur Road
Inviting authority
Executive Engineer L.I.DIvision, Jajpur Road

All Orissa Lift Irrigation Corporation tenders in Jajpur →

Costs

Estimated value: ₹26,39,667; ₹26.40 lakh
EMD / bid security: ₹26,397; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (11)

Contractors should not have been awarded a minimum of 3 works during the current financial year to avail EMD exemption (requires affidavit).
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish required Performance Security within the specified time.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per Works Department O.M. No.67764600022025-17941/W, Dt.08.10.26.
The APS provision is not applicable to Turnkey Tenders.
ISD Value of 1% must be deposited in the form of NSC/Post Office Savings Bank Account/Post Office Time Deposit Account/Kishan Vikas Patra/Deposit Receipt (TDR) of a scheduled bank, pledged in favor of the Executive Engineer, L.I. Division, JAJPUR ROAD.
No Bank Draft/D.D. is accepted for ISD.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.
Security deposit of 5% of the bill will be deducted and refunded 18 months after handing over and final bill payment.
If the contractor fails to rectify defects, the Department may engage another contractor and deduct costs from the security deposit.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed67 requirements extracted21 documents identifiedExtracted from the official tender document

Eligibility

9 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a Truck mounted Mud Rotary Rig for Drilling of TWs.
Contractors must have a valid HT License issued by ELBO.

Show 6 more

Registered with the State Govt. of Odisha or equivalent grade/class registered with other State Govt./Central Govt./M.E.S./Railways or other Govt. undertakings.
For Joint Ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
SC/ST contractors with both Civil & Electrical Licenses may receive price preference.
Bidders registered under other State Govt./M.E.S./Railways/CPWD in equivalent rank may participate but must register under the state PWD before signing the agreement if successful.
The P.A holders of any SC/ST bidders should belong to the SC/ST category only.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

2 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
For TW packages, experience Rig holders must participate in Joint Venture Agreement with the required class of contractor and submit an Experience certificate from an Authority not less than the Rank of Executive Officer of the RIG holder.

Source: Original DTCNView source document

Financial

13 items

Contractors should not have been awarded a minimum of 3 works during the current financial year to avail EMD exemption (requires affidavit).
The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.

Show 10 more

EMD will be forfeited if a successful bidder fails to execute the agreement or furnish required Performance Security within the specified time.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per Works Department O.M. No.67764600022025-17941/W, Dt.08.10.26.
The APS provision is not applicable to Turnkey Tenders.
ISD Value of 1% must be deposited in the form of NSC/Post Office Savings Bank Account/Post Office Time Deposit Account/Kishan Vikas Patra/Deposit Receipt (TDR) of a scheduled bank, pledged in favor of the Executive Engineer, L.I. Division, JAJPUR ROAD.
No Bank Draft/D.D. is accepted for ISD.
Non-entering into agreement shall lead to forfeiture of Earnest Money.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.
Security deposit of 5% of the bill will be deducted and refunded 18 months after handing over and final bill payment.
If the contractor fails to rectify defects, the Department may engage another contractor and deduct costs from the security deposit.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

15 items

Possession of a Truck mounted Mud Rotary Rig for Drilling of TWs.
Erection of 11KV Line, L.T Line & Commissioning of Electrical Substation for power supply to L.I Projects.
Installation of Pump Set, Starter and its energisation.

Show 12 more

Weightage may be given to contractors having their own plants and machineries (Rig & Ancillaries).
Contractor shall employ Engineers/Tech. staff as per norms of the Govt. of Odisha.
Materials for 11 KV line: 55/80 mm2 A.A.A.C. conductor, span length 0.07 km.
Materials for L.T. line: A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, span length 0.03 km.
Sub-stations: 11/0.4 KV, 25 KVA to 100 KVA.
Test certificate of the transformer issued by the manufacturer must be submitted.
All transformers shall be subjected to routine tests as per IS-2026/1977 or its latest amendment.
Transformer oil characteristics must meet specified standards (e.g., density, viscosity, flash point, electric strength).
Lightening arrester must be Metal oxide gapless distribution type, 12 KV rated voltage, 5 KA nominal discharge current, meeting REC Specification No. F-9.
UPVC Pipe, HDPE Pipe and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied must conform to the latest ISI/CPRI specifications, or specifications made by the Executive Engineer.
Bricks must be well burnt, of good quality, approved by the site Engineer, and confirm to the minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

28 items

Bids must be submitted online only.
Last date for online bid submission is Dt. 03.11.26 up to 5:00 P.M.
Bid opening date is Dt. 04.11.26 at 11:00 A.M.

Show 25 more

Offer validity is 180 days from the date of opening of Financial Bids.
Completion period for each work is 90 days from the date of issue of work order.
Compensation for delay is 0.5% of the estimated cost per week, up to a maximum of 10% of the estimated cost.
The successful Tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation.
The cost of the Stamp paper for the agreement will be borne by the Tenderer.
The work will not be sublet without written permission from the Executive Engineer.
The authority reserves the right to increase or decrease the quantity of work items, or reject any/all tenders, or distribute works without assigning reasons.
Contractors are liable to fully indemnify the Department for any compensation under the Workmen's Compensation Act VII of 1993.
Contractors must abide by fair wages clauses and not pay less than the fair wages fixed by the Govt. to laborers.
All taxes, cess, royalties, income taxes, and surcharges (except GST) are to be borne by the bidder; GST will be paid extra.
Royalties for materials utilized will be recovered from the bill based on Govt. fixed rates.
The contractor is responsible for all preliminary works (e.g., GSTs, mixing platforms) and their dismantling and removal at their own cost.
No compensation will be paid for damage due to natural calamities.
No claim for idle labor/machinery/equipment will be entertained.
Interest is not chargeable for dues or additional dues.
The contractor must provide adequate protection measures for completed works and works in progress until handing over.
Dewatering from foundations is at the contractor's cost.
Quantities for items with quoted rates more than 25% of estimated rates cannot be varied by more than 5% without competent authority approval.
Any defect occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
Payment will be made after completion of work, handing over of electric line and substation to TPNODL, and completion of all formalities with TPNODL.
The works bill will be paid after a resolution from Pani Panchayat members confirming work completion and successful trial run.
The contractor must inform the President/Secretary and Pani Panchayat members for commissioning and trial run.
After completion, materials fitted at the project should be handed over to the President/Secretary of the Pani Panchayat.
The electrical works will be handed over to TPNODL for maintenance after completion.
The contractor must sign each page of the tender paper; unsigned tenders will be rejected.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹26,39,667

₹26.40 lakh

EMD / bid security

₹26,397

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (11)

Contractors should not have been awarded a minimum of 3 works during the current financial year to avail EMD exemption (requires affidavit).
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish required Performance Security within the specified time.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per Works Department O.M. No.67764600022025-17941/W, Dt.08.10.26.
The APS provision is not applicable to Turnkey Tenders.
ISD Value of 1% must be deposited in the form of NSC/Post Office Savings Bank Account/Post Office Time Deposit Account/Kishan Vikas Patra/Deposit Receipt (TDR) of a scheduled bank, pledged in favor of the Executive Engineer, L.I. Division, JAJPUR ROAD.
No Bank Draft/D.D. is accepted for ISD.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.
Security deposit of 5% of the bill will be deducted and refunded 18 months after handing over and final bill payment.
If the contractor fails to rectify defects, the Department may engage another contractor and deduct costs from the security deposit.

Source: Original DTCN

Frequently asked questions

PKG68

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

PKG68

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more