What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 06 Nov 2026, 05:00 PM. Bids are scheduled to open on 07 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹26.48 L (₹26,47,617).

How much EMD is required?

The EMD (bid security) is ₹26.5K (₹26,476). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Reputed Contractors/Firms with valid PWD License of required class for Civil Works; Contractors must have a valid HT License issued by ELBO.

What work experience is required?

As extracted from the DTCN: For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate; Bidders must have executed similar type of work in the last five years (weightage given).

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI,Central Circle, Cuttack, LI Division Jajpur Road; the tender inviting authority is the Executive Engineer L.I.DIvision, Jajpur Road.

What documents are required to submit a bid?

The DTCN lists 21 documents, including PWD License, HT License, Rig Owner's Experience Certificates (for TW projects), Rig RC Book (for TW projects), Rig Fitness Certificate (for TW projects), Rig Permit (for TW projects), and 15 more.

OtherLive

PKG65

Jajpur Road, Jajpur Orissa Lift Irrigation CorporationLI Division Jajpur Road

Tender ID 2026_OLIC_144327_70Ref OLIC_02_26_27

Estimated value: ₹26.48 L
EMD: ₹26.5K; Exemption available
Tender fee: ₹7.1K
Work period: —

Closing in

3 days left

06 Nov 2026, 05:00 PM

About this tender

Orissa Lift Irrigation Corporation has invited bids for “PKG65” in Jajpur Road, Jajpur district, Odisha. The estimated tender value is ₹26.48 lakh. Bids must be submitted by 06 Nov 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Done: Tender is currently open
Done: BOQ available · 57 items
Done: DTCN analysed · 53 requirements extracted
Done: 21 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published30 Oct 2026, 12:00 PM
Document downloadUntil 06 Nov 2026
Submission deadline· 3 days left06 Nov 2026, 05:00 PM
Bid opening07 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed53 requirements extracted21 documents identifiedExtracted from the official tender document

This tender from the Odisha Lift Irrigation Corporation Limited (OLIC) invites bids for the drilling, installation, and energization of 76 Lift Irrigation Projects in Jajpur District. The projects, valued between Rs. 24.60 Lakh and Rs. 29.51 Lakh, require contractors with valid PWD and HT licenses, and experience in civil works, drilling, and electrical substation commissioning. Bidders must possess a truck-mounted mud rotary rig or enter into a joint venture with a rig owner.

Eligibility

8 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a valid HT License issued by ELBO.
Contractors must possess a Truck mounted Mud Rotary Rig for Drilling of TWs or submit a joint venture agreement with a rig owner.

Show 5 more

Registered with the State Govt. of Odisha or equivalent grade/class registered with other State Govt. / Central Govt. / M.E.S. / Railways or other Govt. undertakings.
For joint ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
SC/ST contractors with both Civil & Electrical Licenses may receive price preference.
The P.A. holders of any SC/ST bidders should belong to the SC/ST category only.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Bidders must have executed similar type of work in the last five years (weightage given).
For TW packages, experienced Rig holders must participate in a Joint Venture Agreement with the required class of contractor, submitting an experience certificate from an authority not less than the rank of Executive Officer of the Rig holder.

Source: Original DTCNView source document

Financial

9 items

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.

Show 6 more

EMD will be forfeited if the successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
If any submitted documents are found false/fabricated/bogus, the bidder will be blacklisted and EMD forfeited.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per the specified ROPL percentages.
APS shall be treated as part of the performance security and refunded within 7 days of the Completion Certificate/Provisional Completion Certificate.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, with an ISD Value of 1% in the specified forms.
Security deposit of 5% of the bill will be deducted and refunded 18 months after handing over, subject to final bill payment.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

18 items

Contractors having their own plants and machinery (Rig & Ancillaries) will be given weightage.
The work involves erecting 11 K.V. H.T. line, L.T. line, and commissioning 11/0.4 KV substations ranging from 25 KVA to 100 KVA.
Materials for 11 KV line, L.T. line, and substations must be supplied by the contractors as per Annex. B to H.

Show 15 more

The size of conductor for 11 KV line is 55/80 mm2 A.A.A.C. as per TPNODL Estimate, with a span length of 0.07 km.
L.T. line materials use A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, with a span length of 0.03 km.
Contractor must submit test certificates for transformers issued by the manufacturer.
All transformers shall be subjected to routine tests at the manufacturer's work as per IS-2026/1977 or its latest amendment.
Transformer oil must meet specified characteristics including density, viscosity, flash point, pour point, neutralization value, electric strength, dielectric dissipation factor, specific resistance, and oxidation stability.
Lightening arresters must be Metal oxide gapless distribution type, meeting REC Specification No. F-9 for rated voltage, discharge current, reference current, and maximum residual voltage.
Contractor shall employ Engineers/Technical staff as per Govt. of Odisha norms.
Samples of stone, metal, chips, sand, cement, etc., must be deposited for testing and acceptance before procurement.
Mechanical, electro-mechanical, and electrical materials must be inspected at the principal manufacturer's site before dispatch.
All materials supplied by the contractor should be procured from firms in Odisha and approved by the Engineer-in-charge.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
The contractor must arrange necessary tools and plants, Rig & Machineries for efficient execution of work at their own cost.
The materials to be supplied for use in the works should be of ISI specification.
The contractor shall arrange all requisite equipment for testing after completion of work and bear the entire cost.
UPVC pipes supplied must bear ISI mark and CIPET testing certificate from firms in Odisha.

Source: Original DTCNView source document

Contract conditions

15 items

The completion period for each project is 90 days from the date of issue of the work order.
The offer validity period is 180 days from the date of opening of the Financial Bids.
No claim for idle labour/machinery/equipment will be entertained.

Show 12 more

All taxes, cess, royalties, income taxes, and surcharges (except GST) are to be borne by the bidder; GST will be paid extra.
Conditional tenders or tenders containing extraneous conditions will be rejected.
The contract work must not be sublet without written approval from the Executive Engineer.
Compensation for delay is 0.5% of the estimated cost per week, not exceeding 10% of the estimated cost.
If the contractor fails to complete one-fourth, one-half, or three-fourths of the work within the respective timeframes, compensation of 0.3% of the estimated cost per week will be levied.
The contractor is liable to pay compensation under the Workmen's Compensation Act VII of 1993.
The contractor must abide by fair wages clauses and not pay less than the Government-fixed fair wages.
No compensation will be paid for damage due to natural calamities.
Interest is not chargeable for dues or additional dues.
Any defects occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
Payment will be made after completion of work, handing over of electric line and substation to TPNODL, and completion of all formalities with TPNODL.
The contractor must sign each page of the tender paper; failure to do so will result in rejection.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

57 priced items · ₹26.00 L (₹26,00,224)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply56%₹14.48 L
Earthwork & excavation25%₹6.60 L
Electrical10%₹2.53 L
Concrete & RCC5%₹1.17 L
Masonry3%₹88.8K
Reinforcement steel1%₹19.9K

Largest items

By amount

Cost, Supplying of ISI marked 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 for water supply as…Item 1.2 · 870 Mtr₹4.73 L
Construction and erection of 11 /0.4 KV , 25 KVA Double Pole mounted Substation with 5mtrx3mtrx1.5mtr height…Item 2.02 · 1 No₹4.06 L
Fitting and Fixing 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 Pipe including jointing the pi…Item 1.21 · 870 Mtr₹2.99 L
From 0 mtr. to 100th metersItem 3.3 · 90 Per mtr.₹1.90 L
Construction of 3 phase 11 KV HT line as per REC standard confirming to IE Rules 1956 with 300 kg 9 M long PS…Item 2.01 · 0.3 Km.₹1.56 L

Tender details

Tender reference: OLIC_02_26_27
Tender ID: 2026_OLIC_144327_70
District: Jajpur
Location: Jajpur Road
Tender type: Open Tender
Tender category: Works

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 755019

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI,Central Circle, Cuttack
Office
LI Division Jajpur Road
Inviting authority
Executive Engineer L.I.DIvision, Jajpur Road

All Orissa Lift Irrigation Corporation tenders in Jajpur →

Costs

Estimated value: ₹26,47,617; ₹26.48 lakh
EMD / bid security: ₹26,476; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (8)

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if the successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
If any submitted documents are found false/fabricated/bogus, the bidder will be blacklisted and EMD forfeited.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per the specified ROPL percentages.
APS shall be treated as part of the performance security and refunded within 7 days of the Completion Certificate/Provisional Completion Certificate.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, with an ISD Value of 1% in the specified forms.
Security deposit of 5% of the bill will be deducted and refunded 18 months after handing over, subject to final bill payment.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed53 requirements extracted21 documents identifiedExtracted from the official tender document

Eligibility

8 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a valid HT License issued by ELBO.
Contractors must possess a Truck mounted Mud Rotary Rig for Drilling of TWs or submit a joint venture agreement with a rig owner.

Show 5 more

Registered with the State Govt. of Odisha or equivalent grade/class registered with other State Govt. / Central Govt. / M.E.S. / Railways or other Govt. undertakings.
For joint ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
SC/ST contractors with both Civil & Electrical Licenses may receive price preference.
The P.A. holders of any SC/ST bidders should belong to the SC/ST category only.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Bidders must have executed similar type of work in the last five years (weightage given).
For TW packages, experienced Rig holders must participate in a Joint Venture Agreement with the required class of contractor, submitting an experience certificate from an authority not less than the rank of Executive Officer of the Rig holder.

Source: Original DTCNView source document

Financial

9 items

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.

Show 6 more

EMD will be forfeited if the successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
If any submitted documents are found false/fabricated/bogus, the bidder will be blacklisted and EMD forfeited.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per the specified ROPL percentages.
APS shall be treated as part of the performance security and refunded within 7 days of the Completion Certificate/Provisional Completion Certificate.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, with an ISD Value of 1% in the specified forms.
Security deposit of 5% of the bill will be deducted and refunded 18 months after handing over, subject to final bill payment.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

18 items

Contractors having their own plants and machinery (Rig & Ancillaries) will be given weightage.
The work involves erecting 11 K.V. H.T. line, L.T. line, and commissioning 11/0.4 KV substations ranging from 25 KVA to 100 KVA.
Materials for 11 KV line, L.T. line, and substations must be supplied by the contractors as per Annex. B to H.

Show 15 more

The size of conductor for 11 KV line is 55/80 mm2 A.A.A.C. as per TPNODL Estimate, with a span length of 0.07 km.
L.T. line materials use A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, with a span length of 0.03 km.
Contractor must submit test certificates for transformers issued by the manufacturer.
All transformers shall be subjected to routine tests at the manufacturer's work as per IS-2026/1977 or its latest amendment.
Transformer oil must meet specified characteristics including density, viscosity, flash point, pour point, neutralization value, electric strength, dielectric dissipation factor, specific resistance, and oxidation stability.
Lightening arresters must be Metal oxide gapless distribution type, meeting REC Specification No. F-9 for rated voltage, discharge current, reference current, and maximum residual voltage.
Contractor shall employ Engineers/Technical staff as per Govt. of Odisha norms.
Samples of stone, metal, chips, sand, cement, etc., must be deposited for testing and acceptance before procurement.
Mechanical, electro-mechanical, and electrical materials must be inspected at the principal manufacturer's site before dispatch.
All materials supplied by the contractor should be procured from firms in Odisha and approved by the Engineer-in-charge.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
The contractor must arrange necessary tools and plants, Rig & Machineries for efficient execution of work at their own cost.
The materials to be supplied for use in the works should be of ISI specification.
The contractor shall arrange all requisite equipment for testing after completion of work and bear the entire cost.
UPVC pipes supplied must bear ISI mark and CIPET testing certificate from firms in Odisha.

Source: Original DTCNView source document

Contract conditions

15 items

The completion period for each project is 90 days from the date of issue of the work order.
The offer validity period is 180 days from the date of opening of the Financial Bids.
No claim for idle labour/machinery/equipment will be entertained.

Show 12 more

All taxes, cess, royalties, income taxes, and surcharges (except GST) are to be borne by the bidder; GST will be paid extra.
Conditional tenders or tenders containing extraneous conditions will be rejected.
The contract work must not be sublet without written approval from the Executive Engineer.
Compensation for delay is 0.5% of the estimated cost per week, not exceeding 10% of the estimated cost.
If the contractor fails to complete one-fourth, one-half, or three-fourths of the work within the respective timeframes, compensation of 0.3% of the estimated cost per week will be levied.
The contractor is liable to pay compensation under the Workmen's Compensation Act VII of 1993.
The contractor must abide by fair wages clauses and not pay less than the Government-fixed fair wages.
No compensation will be paid for damage due to natural calamities.
Interest is not chargeable for dues or additional dues.
Any defects occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
Payment will be made after completion of work, handing over of electric line and substation to TPNODL, and completion of all formalities with TPNODL.
The contractor must sign each page of the tender paper; failure to do so will result in rejection.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹26,47,617

₹26.48 lakh

EMD / bid security

₹26,476

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (8)

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if the successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
If any submitted documents are found false/fabricated/bogus, the bidder will be blacklisted and EMD forfeited.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per the specified ROPL percentages.
APS shall be treated as part of the performance security and refunded within 7 days of the Completion Certificate/Provisional Completion Certificate.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, with an ISD Value of 1% in the specified forms.
Security deposit of 5% of the bill will be deducted and refunded 18 months after handing over, subject to final bill payment.

Source: Original DTCN

Frequently asked questions

PKG65

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

PKG65

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more