What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 06 Nov 2026, 05:00 PM. Bids are scheduled to open on 07 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹29.26 L (₹29,26,152).

How much EMD is required?

The EMD (bid security) is ₹29.3K (₹29,262). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Reputed Contractors/Firms with valid PWD License of required class for Civil Works; Contractors must have a Truck mounted Mud Rotary Rig for Drilling of TWs or a Joint Venture Agreement with a rig owner.

What work experience is required?

As extracted from the DTCN: For TW projects, if the bidder does not own a rig, a joint venture agreement with a rig owner is required, executed in the court of First Class Magistrate/Executive Magistrate; Contractors should have executed similar type of work in the last five years (weightage given).

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI,Central Circle, Cuttack, LI Division Jajpur Road; the tender inviting authority is the Executive Engineer L.I.DIvision, Jajpur Road.

What documents are required to submit a bid?

The DTCN lists 23 documents, including PWD License (Civil), HT License (Electrical), Rig Owner's Experience Certificates (for TW projects), Rig RC Book (for TW projects), Rig Fitness Certificate (for TW projects), Rig Permit (for TW projects), and 17 more.

OtherLive

PKG63

Jajpur Road, Jajpur Orissa Lift Irrigation CorporationLI Division Jajpur Road

Tender ID 2026_OLIC_144327_67Ref OLIC_02_26_27

Estimated value: ₹29.26 L
EMD: ₹29.3K; Exemption available
Tender fee: ₹7.1K
Work period: —

Closing in

4 days left

06 Nov 2026, 05:00 PM

About this tender

Orissa Lift Irrigation Corporation has invited bids for “PKG63” in Jajpur Road, Jajpur district, Odisha. The estimated tender value is ₹29.26 lakh. Bids must be submitted by 06 Nov 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Done: Tender is currently open
Done: BOQ available · 58 items
Done: DTCN analysed · 54 requirements extracted
Done: 23 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published30 Oct 2026, 12:00 PM
Document downloadUntil 06 Nov 2026
Submission deadline· 4 days left06 Nov 2026, 05:00 PM
Bid opening07 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed54 requirements extracted23 documents identifiedExtracted from the official tender document

This tender from the Odisha Lift Irrigation Corporation Ltd. invites bids for the drilling, installation, and energization of 76 Lift Irrigation Projects in Jajpur District. The work is on a turnkey basis, including civil works, drilling of tube wells, erection of 11KV and LT lines, and commissioning of electrical substations. Estimated costs range from Rs. 24.60 Lakh to Rs. 29.51 Lakh per package, with a completion period of 90 days for each project. Contractors must have valid PWD and HT Licenses and possess a truck-mounted mud rotary rig or enter a joint venture with a rig owner.

Eligibility

9 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a Truck mounted Mud Rotary Rig for Drilling of TWs or a Joint Venture Agreement with a rig owner.
Registered with State Govt. of Odisha or equivalent grade/class registered with other State Govt./Central Govt./M.E.S./Railways or other Govt. undertakings.

Show 6 more

Must have Registered HT License issued by ELBO.
Registered in the State portal and possessing compatible digital signature certificate for online bidding.
For Joint Ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
P.A holders of any SC/ST bidders should belong to SC/ST category only.
Defaulter contractors are not allowed to participate.
SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference.

Source: Original DTCNView source document

Experience

3 items

For TW projects, if the bidder does not own a rig, a joint venture agreement with a rig owner is required, executed in the court of First Class Magistrate/Executive Magistrate.
Contractors should have executed similar type of work in the last five years (weightage given).
For TW packages, experienced Rig holders must participate in Joint Venture Agreement with the required class of contractor, submitting an experience certificate from an authority not less than the rank of Executive Officer of the RIG holder.

Source: Original DTCNView source document

Financial

9 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if the successful bidder fails to execute the agreement or furnish required Performance Security within the specified time.

Show 6 more

EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per detailed government guidelines.
APS is not applicable to Turnkey Tenders.
Security deposit of 2% of the quoted value of work is required, with the balance made up by deducting 5% from each payment.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

15 items

Contractors having their own plants and machineries (Rig & Ancillaries) will be given weightage.
Possession of a Truck mounted Mud Rotary Rig for Drilling of TWs, or a Joint Venture Agreement with a rig owner.
Erection of 11 K.V. H.T. line, L.T. line, and commissioning of 11/0.4 KV substations (25 KVA to 100 KVA).

Show 12 more

Supply of materials as mentioned in Annex. B to H for electrical works.
Conductor size for 11 KV line: 55/80 mm2 A.A.A.C. as per TPNODL Estimate, with a span length of 0.07 km.
Materials for LT line with A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, with a span length of 0.03 km.
Submission of test certificate of the transformer issued by the manufacturer.
Transformers must undergo routine tests at the manufacturer's work as per IS-2026/1977 or latest amendment.
Transformer oil characteristics must meet specified standards for appearance, density, viscosity, flash point, pour point, neutralization value, electric strength, dielectric dissipation factor, specific resistance, and oxidation stability.
Lightening arresters must be Metal oxide gapless distribution type, meeting REC Specification No. F-9 for rated voltage, discharge current, reference current, reference voltage, residual voltage, continuous operative voltage, impulse withstand, and insulation withstand.
Materials for cut points, guarding, and line D.P. for 3 phase 11 KV line must adhere to specified quantities and types.
Contractor shall employ Engineers/Tech. staff as per norms of the Govt. of Odisha.
UPVC Pipe, HDPE Pipe and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied must conform to the latest ISI / CPRI specifications, or specifications made by the Executive Engineer.
Bricks used must be well burnt, of good quality, approved by the site Engineer, and confirm to minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

18 items

The completion period for each project is 90 days from the date of issue of the work order.
Tenders remain valid for 180 days from the date of opening of Financial Bids.
The successful bidder must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation.

Show 15 more

The defect liability period is 18 months after completion of works.
Compensation for delay is 0.5% of the estimated cost per week, not exceeding 10% of the estimated cost.
No claim for idle labour/machinery/equipment will be entertained.
All taxes, cess, royalties, income taxes, and surcharges (except GST) are to be borne by the bidder; GST will be paid extra.
The contractor must abide by fair wages clauses and not pay less than the Government-fixed fair wages.
No compensation will be paid for damage due to natural calamities.
The contract work should not be sublet without written approval.
Payment will be made after successful completion of work, testing, commissioning, handing over to the concerned Pani Panchayat, and completion of all formalities with TPNODL.
Any defects occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
The contractor is responsible for providing adequate protection measures for completed and in-progress works against damages until handing over.
The contractor must arrange for water supply, curing of masonry works, and sanitary arrangements for labour camps at their own cost.
The contractor must arrange necessary tools and plants, Rig & Machineries at their own cost.
The contractor must pay royalties to the Govt. for materials used and produce supporting documents.
If abnormally low rates are quoted for some items, the Corporation may withhold the differential cost from other payments until those items are completed.
The contractor must sign each page of the tender paper; unsigned papers will be rejected.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

58 priced items · ₹28.79 L (₹28,78,759)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply55%₹15.90 L
Earthwork & excavation24%₹6.87 L
Electrical12%₹3.54 L
Concrete & RCC4%₹1.24 L
Masonry3%₹88.8K
Reinforcement steel1%₹21.0K

Largest items

By amount

Cost, Supplying of ISI marked 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 for water supply as…Item 1.2 · 956 Mtr₹5.19 L
Construction and erection of 11 /0.4 KV , 25 KVA Double Pole mounted Substation with 5mtrx3mtrx1.5mtr height…Item 2.02 · 1 No₹4.06 L
Fitting and Fixing 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 Pipe including jointing the pi…Item 1.21 · 956 Mtr₹3.29 L
Construction of 3 phase 11 KV HT line as per REC standard confirming to IE Rules 1956 with 300 kg 9 M long PS…Item 2.01 · 0.4 Km.₹2.08 L
From 0 mtr. to 100th metersItem 3.03 · 90 Per mtr.₹1.90 L

Tender details

Tender reference: OLIC_02_26_27
Tender ID: 2026_OLIC_144327_67
District: Jajpur
Location: Jajpur Road
Tender type: Open Tender
Tender category: Works

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 755019

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI,Central Circle, Cuttack
Office
LI Division Jajpur Road
Inviting authority
Executive Engineer L.I.DIvision, Jajpur Road

All Orissa Lift Irrigation Corporation tenders in Jajpur →

Costs

Estimated value: ₹29,26,152; ₹29.26 lakh
EMD / bid security: ₹29,262; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (8)

EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if the successful bidder fails to execute the agreement or furnish required Performance Security within the specified time.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per detailed government guidelines.
APS is not applicable to Turnkey Tenders.
Security deposit of 2% of the quoted value of work is required, with the balance made up by deducting 5% from each payment.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed54 requirements extracted23 documents identifiedExtracted from the official tender document

Eligibility

9 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a Truck mounted Mud Rotary Rig for Drilling of TWs or a Joint Venture Agreement with a rig owner.
Registered with State Govt. of Odisha or equivalent grade/class registered with other State Govt./Central Govt./M.E.S./Railways or other Govt. undertakings.

Show 6 more

Must have Registered HT License issued by ELBO.
Registered in the State portal and possessing compatible digital signature certificate for online bidding.
For Joint Ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
P.A holders of any SC/ST bidders should belong to SC/ST category only.
Defaulter contractors are not allowed to participate.
SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference.

Source: Original DTCNView source document

Experience

3 items

For TW projects, if the bidder does not own a rig, a joint venture agreement with a rig owner is required, executed in the court of First Class Magistrate/Executive Magistrate.
Contractors should have executed similar type of work in the last five years (weightage given).
For TW packages, experienced Rig holders must participate in Joint Venture Agreement with the required class of contractor, submitting an experience certificate from an authority not less than the rank of Executive Officer of the RIG holder.

Source: Original DTCNView source document

Financial

9 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if the successful bidder fails to execute the agreement or furnish required Performance Security within the specified time.

Show 6 more

EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per detailed government guidelines.
APS is not applicable to Turnkey Tenders.
Security deposit of 2% of the quoted value of work is required, with the balance made up by deducting 5% from each payment.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

15 items

Contractors having their own plants and machineries (Rig & Ancillaries) will be given weightage.
Possession of a Truck mounted Mud Rotary Rig for Drilling of TWs, or a Joint Venture Agreement with a rig owner.
Erection of 11 K.V. H.T. line, L.T. line, and commissioning of 11/0.4 KV substations (25 KVA to 100 KVA).

Show 12 more

Supply of materials as mentioned in Annex. B to H for electrical works.
Conductor size for 11 KV line: 55/80 mm2 A.A.A.C. as per TPNODL Estimate, with a span length of 0.07 km.
Materials for LT line with A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, with a span length of 0.03 km.
Submission of test certificate of the transformer issued by the manufacturer.
Transformers must undergo routine tests at the manufacturer's work as per IS-2026/1977 or latest amendment.
Transformer oil characteristics must meet specified standards for appearance, density, viscosity, flash point, pour point, neutralization value, electric strength, dielectric dissipation factor, specific resistance, and oxidation stability.
Lightening arresters must be Metal oxide gapless distribution type, meeting REC Specification No. F-9 for rated voltage, discharge current, reference current, reference voltage, residual voltage, continuous operative voltage, impulse withstand, and insulation withstand.
Materials for cut points, guarding, and line D.P. for 3 phase 11 KV line must adhere to specified quantities and types.
Contractor shall employ Engineers/Tech. staff as per norms of the Govt. of Odisha.
UPVC Pipe, HDPE Pipe and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied must conform to the latest ISI / CPRI specifications, or specifications made by the Executive Engineer.
Bricks used must be well burnt, of good quality, approved by the site Engineer, and confirm to minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

18 items

The completion period for each project is 90 days from the date of issue of the work order.
Tenders remain valid for 180 days from the date of opening of Financial Bids.
The successful bidder must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation.

Show 15 more

The defect liability period is 18 months after completion of works.
Compensation for delay is 0.5% of the estimated cost per week, not exceeding 10% of the estimated cost.
No claim for idle labour/machinery/equipment will be entertained.
All taxes, cess, royalties, income taxes, and surcharges (except GST) are to be borne by the bidder; GST will be paid extra.
The contractor must abide by fair wages clauses and not pay less than the Government-fixed fair wages.
No compensation will be paid for damage due to natural calamities.
The contract work should not be sublet without written approval.
Payment will be made after successful completion of work, testing, commissioning, handing over to the concerned Pani Panchayat, and completion of all formalities with TPNODL.
Any defects occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
The contractor is responsible for providing adequate protection measures for completed and in-progress works against damages until handing over.
The contractor must arrange for water supply, curing of masonry works, and sanitary arrangements for labour camps at their own cost.
The contractor must arrange necessary tools and plants, Rig & Machineries at their own cost.
The contractor must pay royalties to the Govt. for materials used and produce supporting documents.
If abnormally low rates are quoted for some items, the Corporation may withhold the differential cost from other payments until those items are completed.
The contractor must sign each page of the tender paper; unsigned papers will be rejected.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹29,26,152

₹29.26 lakh

EMD / bid security

₹29,262

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (8)

EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if the successful bidder fails to execute the agreement or furnish required Performance Security within the specified time.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be calculated on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, as per detailed government guidelines.
APS is not applicable to Turnkey Tenders.
Security deposit of 2% of the quoted value of work is required, with the balance made up by deducting 5% from each payment.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
1% of the gross amount of the contractor's bill will be deducted towards labour cess.

Source: Original DTCN

Frequently asked questions

PKG63

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

PKG63

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more