What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 06 Nov 2026, 05:00 PM. Bids are scheduled to open on 07 Nov 2026, 02:00 PM.

What is the estimated value of this tender?

The estimated tender value is ₹26.81 L (₹26,80,697).

How much EMD is required?

The EMD (bid security) is ₹26.8K (₹26,807). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Reputed Contractors/Firms with valid PWD License of required class for Civil Works; Contractors must have a valid HT License issued by ELBO.

What work experience is required?

As extracted from the DTCN: For TW projects, contractors with no own rig must submit a joint venture agreement with a rig owner, executed in the court of First Class Magistrate/Executive Magistrate; Contractors having work experience of drilling works and owning a Rig are to participate in Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years for ** TW Packages.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI,Central Circle, Cuttack, LI Division Jajpur Road; the tender inviting authority is the Executive Engineer L.I.DIvision, Jajpur Road.

What documents are required to submit a bid?

The DTCN lists 29 documents, including PWD License (Civil), HT License (Electrical), Rig Owner's Experience Certificates (for TW projects, if not owning a rig), Rig RC Book (for TW projects, if owning a rig), Rig Fitness Certificate (for TW projects, if owning a rig), Rig Permit (for TW projects, if owning a rig), and 23 more.

OtherLive

PKG58

Jajpur Road, Jajpur Orissa Lift Irrigation CorporationLI Division Jajpur Road

Tender ID 2026_OLIC_144327_62Ref OLIC_02_26_27

Estimated value: ₹26.81 L
EMD: ₹26.8K; Exemption available
Tender fee: ₹7.1K
Work period: —

Closing in

4 days left

06 Nov 2026, 05:00 PM

About this tender

Orissa Lift Irrigation Corporation has invited bids for “PKG58” in Jajpur Road, Jajpur district, Odisha. The estimated tender value is ₹26.81 lakh. Bids must be submitted by 06 Nov 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Done: Tender is currently open
Done: BOQ available · 61 items
Done: DTCN analysed · 59 requirements extracted
Done: 29 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published29 Oct 2026, 02:00 PM
Document downloadUntil 06 Nov 2026
Submission deadline· 4 days left06 Nov 2026, 05:00 PM
Bid opening07 Nov 2026, 02:00 PM

Tender intelligence

Eligibility & bid requirements

DTCN analysed59 requirements extracted29 documents identifiedExtracted from the official tender document

This tender from the Odisha Lift Irrigation Corporation Limited (OLIC) invites bids for 76 packages of drilling, installation, and energization of Lift Irrigation Projects on a Turnkey basis in Jajpur District. The work involves civil works, drilling of Tube Wells (TWs), erection of 11KV and LT lines, and commissioning of electrical substations. Estimated costs range from Rs. 24.60 Lakh to Rs. 29.51 Lakh per package, with a completion period of 90 days for each. Contractors must possess valid PWD and HT Licenses and, for TW projects, either own a truck-mounted mud rotary rig or enter a joint venture with a rig owner.

Eligibility

9 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a valid HT License issued by ELBO.
Registered with the State Govt. of Odisha or equivalent grade/class registered with other State Govt./Central Govt./M.E.S./Railways or other Govt. undertakings.

Show 6 more

Possess a truck-mounted Mud Rotary Rig for Drilling of TWs or enter a joint venture with a rig owner for TW projects.
In joint ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference.
Bidders registered under other State Govt./M.E.S./Railways/CPWD in equivalent rank may participate but successful bidders must register under the state PWD before signing the agreement.
The PA holders of any SC/ST bidders should belong to the SC/ST category only.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

2 items

For TW projects, contractors with no own rig must submit a joint venture agreement with a rig owner, executed in the court of First Class Magistrate/Executive Magistrate.
Contractors having work experience of drilling works and owning a Rig are to participate in Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years for ** TW Packages.

Source: Original DTCNView source document

Financial

16 items

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.

Show 13 more

EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted statements, documents, or certificates are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the Rounding Off of Percentage Less (ROPL).
APS is not required if ROPL is up to (-)10%.
APS increases incrementally for ROPL below (-)10%, with specific percentages for different ROPL ranges.
The additional performance security shall be treated as part of the performance security.
The provision of additional performance security is applicable to all forms of tender except Turnkey Tender.
Successful bidders must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing ISD Value of 1% in specified forms.
No Bank Draft/D.D. is accepted for ISD.
Non-entering into agreement shall lead to forfeiture of Earnest Money.
The EMD is liable to be forfeited if the bidder backs out from the offer before acceptance.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
If the contractor fails to rectify defects, the department may engage another contractor and deduct costs from the security deposit.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

13 items

Contractors must have a truck-mounted Mud Rotary Rig for Drilling of TWs, or a joint venture with a rig owner for rig provision.
For * TW projects, Rig Owner’s Experience Certificates with RC Book, Fitness, Permit, Insurance, Pollution Certificates are required.
For ** TW Packages, Rig RC Book, Fitness, Permit, Insurance, Pollution Certificates are required.

Show 10 more

Contractor shall employ Engineers/Tech. staff as per norms of the Govt. of Odisha.
The work involves erecting 11 K.V. H.T. line, L.T. line, and commissioning of 11/0.4 KV substations (25 KVA to 100 KVA).
Materials for 11 KV line: 55/80 mm2 A.A.A.C. conductor, span length 0.07 km.
Materials for L.T. line: A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, span length 0.03 km.
Transformers must be subjected to routine tests at the manufacturer's work as per IS-2026/1977 or latest amendment.
Transformer oil characteristics must meet specified standards for appearance, density, viscosity, flash point, pour point, neutralization value, electric strength, dielectric dissipation factor, specific resistance, oxidation stability, and water content.
Lightening arresters must be Metal oxide gapless distribution type, meeting REC Specification No. F-9 for rated voltage, discharge current, reference current, reference voltage, residual voltage, continuous operative voltage, impulse withstand, and insulation withstand.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
All materials supplied by the contractor should conform to the latest ISI/CPRI specifications, or specifications made by the Executive Engineer.
Bricks should be well burnt, of good quality, approved by the site Engineer, and confirm to minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

19 items

The completion period for each L.I. Project is 90 days from the date of issue of the work order.
The offer validity is 180 days from the date of opening of the Financial Bids.
If multiple bids are lowest, a transparent lottery system will be used to finalize the tender.

Show 16 more

The cost of the Stamp paper for the agreement will be borne by the Tenderer.
The contractor will be responsible for payment of all royalties, local taxes, Octroi Charges, Ferry & Tollage charges.
All taxes, cess, royalties, income taxes, and surcharges will be borne by the bidder, except GST which will be paid extra.
Conditional tenders or tenders with extraneous conditions will be rejected.
Any defect occurring within 18 months of commissioning must be rectified by the Contractor within 7 days.
No compensation will be paid for damages due to natural calamities; the contractor must make arrangements at their own cost.
No claim for idle labour/machinery/equipment will be entertained.
The contract work should not be sublet without written approval; otherwise, the contract may be rescinded.
The authority reserves the right to increase or decrease quantities of work items; no compensation will be given, only extension of time if necessary.
The work may be split and distributed among several contractors; no compensation will be given.
The contractor must abide by fair wages clauses and the latest minimum wages Act.
Payment will be made after successful completion of work, testing, commissioning, handing over to Pani Panchayat, and completion of all formalities with TPNODL.
The contractor must sign each page of the tender paper; unsigned tenders will be rejected.
Damages to government or private property during pipeline work must be compensated by the contractor at their own cost.
No interest is chargeable for dues or additional dues.
If abnormally low rates are quoted for some items, the Corporation may withhold the differential cost from other payments until those items are completed.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

61 priced items · ₹26.33 L (₹26,33,304)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply56%₹14.72 L
Earthwork & excavation23%₹5.95 L
Electrical13%₹3.55 L
Concrete & RCC4%₹92.5K
Masonry3%₹89.6K
Reinforcement steel1%₹15.8K

Largest items

By amount

Construction and erection of 11 /0.4 KV , 25 KVA Double Pole mounted Substation with 5mtrx3mtrx1.5mtr height…Item 2.02 · 1 No₹4.06 L
Cost, Supplying of ISI marked 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 for water supply as…Item 1.2 · 597 Mtr₹3.24 L
200mm Ø SCHEDULE 80 casing pipe (As per EPM Rate order no.4415 dated 25.10.2024)Item 3.05 · 150 Mtr₹2.37 L
From 0 mtr. to 100th metersItem 3.03 · 100 Per mtr.₹2.11 L
Construction of 3 phase 11 KV HT line as per REC standard confirming to IE Rules 1956 with 300 kg 9 M long PS…Item 2.01 · 0.4 Km.₹2.08 L

Tender details

Tender reference: OLIC_02_26_27
Tender ID: 2026_OLIC_144327_62
District: Jajpur
Location: Jajpur Road
Tender type: Open Tender
Tender category: Works

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 755019

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI,Central Circle, Cuttack
Office
LI Division Jajpur Road
Inviting authority
Executive Engineer L.I.DIvision, Jajpur Road

All Orissa Lift Irrigation Corporation tenders in Jajpur →

Costs

Estimated value: ₹26,80,697; ₹26.81 lakh
EMD / bid security: ₹26,807; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (14)

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted statements, documents, or certificates are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the Rounding Off of Percentage Less (ROPL).
APS is not required if ROPL is up to (-)10%.
APS increases incrementally for ROPL below (-)10%, with specific percentages for different ROPL ranges.
The additional performance security shall be treated as part of the performance security.
The provision of additional performance security is applicable to all forms of tender except Turnkey Tender.
Successful bidders must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing ISD Value of 1% in specified forms.
No Bank Draft/D.D. is accepted for ISD.
The EMD is liable to be forfeited if the bidder backs out from the offer before acceptance.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
If the contractor fails to rectify defects, the department may engage another contractor and deduct costs from the security deposit.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed59 requirements extracted29 documents identifiedExtracted from the official tender document

Eligibility

9 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a valid HT License issued by ELBO.
Registered with the State Govt. of Odisha or equivalent grade/class registered with other State Govt./Central Govt./M.E.S./Railways or other Govt. undertakings.

Show 6 more

Possess a truck-mounted Mud Rotary Rig for Drilling of TWs or enter a joint venture with a rig owner for TW projects.
In joint ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference.
Bidders registered under other State Govt./M.E.S./Railways/CPWD in equivalent rank may participate but successful bidders must register under the state PWD before signing the agreement.
The PA holders of any SC/ST bidders should belong to the SC/ST category only.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

2 items

For TW projects, contractors with no own rig must submit a joint venture agreement with a rig owner, executed in the court of First Class Magistrate/Executive Magistrate.
Contractors having work experience of drilling works and owning a Rig are to participate in Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years for ** TW Packages.

Source: Original DTCNView source document

Financial

16 items

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.

Show 13 more

EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted statements, documents, or certificates are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the Rounding Off of Percentage Less (ROPL).
APS is not required if ROPL is up to (-)10%.
APS increases incrementally for ROPL below (-)10%, with specific percentages for different ROPL ranges.
The additional performance security shall be treated as part of the performance security.
The provision of additional performance security is applicable to all forms of tender except Turnkey Tender.
Successful bidders must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing ISD Value of 1% in specified forms.
No Bank Draft/D.D. is accepted for ISD.
Non-entering into agreement shall lead to forfeiture of Earnest Money.
The EMD is liable to be forfeited if the bidder backs out from the offer before acceptance.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
If the contractor fails to rectify defects, the department may engage another contractor and deduct costs from the security deposit.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

13 items

Contractors must have a truck-mounted Mud Rotary Rig for Drilling of TWs, or a joint venture with a rig owner for rig provision.
For * TW projects, Rig Owner’s Experience Certificates with RC Book, Fitness, Permit, Insurance, Pollution Certificates are required.
For ** TW Packages, Rig RC Book, Fitness, Permit, Insurance, Pollution Certificates are required.

Show 10 more

Contractor shall employ Engineers/Tech. staff as per norms of the Govt. of Odisha.
The work involves erecting 11 K.V. H.T. line, L.T. line, and commissioning of 11/0.4 KV substations (25 KVA to 100 KVA).
Materials for 11 KV line: 55/80 mm2 A.A.A.C. conductor, span length 0.07 km.
Materials for L.T. line: A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, span length 0.03 km.
Transformers must be subjected to routine tests at the manufacturer's work as per IS-2026/1977 or latest amendment.
Transformer oil characteristics must meet specified standards for appearance, density, viscosity, flash point, pour point, neutralization value, electric strength, dielectric dissipation factor, specific resistance, oxidation stability, and water content.
Lightening arresters must be Metal oxide gapless distribution type, meeting REC Specification No. F-9 for rated voltage, discharge current, reference current, reference voltage, residual voltage, continuous operative voltage, impulse withstand, and insulation withstand.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
All materials supplied by the contractor should conform to the latest ISI/CPRI specifications, or specifications made by the Executive Engineer.
Bricks should be well burnt, of good quality, approved by the site Engineer, and confirm to minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

19 items

The completion period for each L.I. Project is 90 days from the date of issue of the work order.
The offer validity is 180 days from the date of opening of the Financial Bids.
If multiple bids are lowest, a transparent lottery system will be used to finalize the tender.

Show 16 more

The cost of the Stamp paper for the agreement will be borne by the Tenderer.
The contractor will be responsible for payment of all royalties, local taxes, Octroi Charges, Ferry & Tollage charges.
All taxes, cess, royalties, income taxes, and surcharges will be borne by the bidder, except GST which will be paid extra.
Conditional tenders or tenders with extraneous conditions will be rejected.
Any defect occurring within 18 months of commissioning must be rectified by the Contractor within 7 days.
No compensation will be paid for damages due to natural calamities; the contractor must make arrangements at their own cost.
No claim for idle labour/machinery/equipment will be entertained.
The contract work should not be sublet without written approval; otherwise, the contract may be rescinded.
The authority reserves the right to increase or decrease quantities of work items; no compensation will be given, only extension of time if necessary.
The work may be split and distributed among several contractors; no compensation will be given.
The contractor must abide by fair wages clauses and the latest minimum wages Act.
Payment will be made after successful completion of work, testing, commissioning, handing over to Pani Panchayat, and completion of all formalities with TPNODL.
The contractor must sign each page of the tender paper; unsigned tenders will be rejected.
Damages to government or private property during pipeline work must be compensated by the contractor at their own cost.
No interest is chargeable for dues or additional dues.
If abnormally low rates are quoted for some items, the Corporation may withhold the differential cost from other payments until those items are completed.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹26,80,697

₹26.81 lakh

EMD / bid security

₹26,807

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (14)

Intending Engineering Contractors seeking EMD exemption must furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted statements, documents, or certificates are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the Rounding Off of Percentage Less (ROPL).
APS is not required if ROPL is up to (-)10%.
APS increases incrementally for ROPL below (-)10%, with specific percentages for different ROPL ranges.
The additional performance security shall be treated as part of the performance security.
The provision of additional performance security is applicable to all forms of tender except Turnkey Tender.
Successful bidders must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing ISD Value of 1% in specified forms.
No Bank Draft/D.D. is accepted for ISD.
The EMD is liable to be forfeited if the bidder backs out from the offer before acceptance.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.
If the contractor fails to rectify defects, the department may engage another contractor and deduct costs from the security deposit.

Source: Original DTCN

Frequently asked questions

PKG58

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

PKG58

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more