What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 06 Nov 2026, 05:00 PM. Bids are scheduled to open on 07 Nov 2026, 02:00 PM.

What is the estimated value of this tender?

The estimated tender value is ₹27.66 L (₹27,65,895).

How much EMD is required?

The EMD (bid security) is ₹27.7K (₹27,659). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Reputed Contractors/Firms with valid PWD License of required class for Civil Works; Contractors must have a registered HT License issued by ELBO.

What work experience is required?

As extracted from the DTCN: For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate; Contractors with work experience of drilling works, having their own Rig, are to participate in a Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI,Central Circle, Cuttack, LI Division Jajpur Road; the tender inviting authority is the Executive Engineer L.I.DIvision, Jajpur Road.

What documents are required to submit a bid?

The DTCN lists 22 documents, including PWD License (Civil Works), Registered HT License (Electrical), Rig Documents (Rig Owner’s Experience Certificates with RC Book, Fitness, Permit, Insurance, Pollution Certificates) for * TW projects, Rig Documents (Rig RC Book, Fitness, Permit, Insurance, Pollution Certificates) for ** TW packages, Experience Certificate (issued by competent authority), GST Registration certificate, and 16 more.

OtherLive

PKG56

Jajpur Road, Jajpur Orissa Lift Irrigation CorporationLI Division Jajpur Road

Tender ID 2026_OLIC_144327_60Ref OLIC_02_26_27

Estimated value: ₹27.66 L
EMD: ₹27.7K; Exemption available
Tender fee: ₹7.1K
Work period: —

Closing in

3 days left

06 Nov 2026, 05:00 PM

About this tender

Orissa Lift Irrigation Corporation has invited bids for “PKG56” in Jajpur Road, Jajpur district, Odisha. The estimated tender value is ₹27.66 lakh. Bids must be submitted by 06 Nov 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Done: Tender is currently open
Done: BOQ available · 57 items
Done: DTCN analysed · 65 requirements extracted
Done: 22 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published29 Oct 2026, 02:00 PM
Document downloadUntil 06 Nov 2026
Submission deadline· 3 days left06 Nov 2026, 05:00 PM
Bid opening07 Nov 2026, 02:00 PM

Tender intelligence

Eligibility & bid requirements

DTCN analysed65 requirements extracted22 documents identifiedExtracted from the official tender document

This tender from the Odisha Lift Irrigation Corporation Limited, Jajpur Road, invites bids for 76 packages of drilling, installation, and energization of Lift Irrigation Projects on a Turnkey basis in Jajpur District. The work involves civil works, drilling of tube wells (TWs), erection of 11KV and LT lines, and commissioning of electrical substations. Contractors must have a valid PWD license for civil works, a registered HT license, and a truck-mounted mud rotary rig for drilling, or a joint venture agreement with a rig owner.

Eligibility

8 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a registered HT License issued by ELBO.
Contractors must be registered in the State portal and possess a compatible digital signature certificate for online bidding.

Show 5 more

Contractors must have a Truck mounted Mud Rotary Rig for Drilling of TWs or a joint venture agreement with a rig owner.
Contractors registered under other State Govt. / M.E.s /Railways /CPWD in equivalent rank may participate, but successful bidders must register under the state PWD before signing the agreement.
In a joint venture, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
The P.A. holders of any SC/ST bidders should belong to the SC/ST category only.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Contractors with work experience of drilling works, having their own Rig, are to participate in a Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years.
Experience certificates should be obtained from an authority not less than the rank of an Executive Officer of the RIG holder.

Source: Original DTCNView source document

Financial

16 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference and EMD exemption (if they furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year)
EMD is 1% of the Estimated Cost, to be deposited online.

Show 13 more

EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, with specific calculation rules based on the 'Rounding Off of Percentage Less (ROPL)'.
APS is not required if ROPL is up to (-)10%.
APS calculation varies for ROPL below (-)10% to (-)20%, below (-)20% to (-)30%, and below (-)30% or more.
APS shall be treated as part of the performance security and is applicable to all forms of tender except Turnkey Tender.
APS shall be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days after receipt of Letter of Intimation, with a 1% ISD Value deposit.
Non-entering into agreement shall lead to forfeiture of Earnest Money.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
1% / 2% (as applicable) of the gross bill amount will be deducted towards income tax, plus surcharge and cess.
1% of the gross bill amount will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

18 items

Possession of a Truck mounted Mud Rotary Rig for Drilling of TWs.
For * TW projects, Rig Owner’s Experience Certificates with RC Book, Fitness, Permit, Insurance, Pollution Certificates are required.
For ** TW packages, Rig RC Book, Fitness, Permit, Insurance, Pollution Certificates are required.

Show 15 more

Weightage may be given to contractors having their own plants and machinery (Rig & Ancillaries).
Contractor shall employ Engineers/Technical staff as per norms of the Govt. of Odisha.
The work involves erecting 11 K.V. H.T. line, L.T. line, and commissioning of 11/0.4 KV substations ranging from 25 KVA to 100 KVA.
Materials for 11 KV line: 55/80 mm2 A.A.A.C. conductor, span length 0.07 km (may vary).
Materials for L.T. line: A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, span length 0.03 km (may vary).
Transformer test certificates issued by the manufacturer are required.
Transformer oil characteristics must meet specified standards (e.g., density, viscosity, flash point, breakdown voltage).
Lightening arrester technical particulars must meet REC Specification No. F-9 (e.g., type, rated voltage, discharge current).
Materials for cut points, guarding, and line D.P. for 11 KV overhead lines must adhere to specified quantities and types.
All materials supplied by the contractor should be procured from firms in Odisha and approved by the Engineer-in-charge.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
UPVC pipes must bear ISI mark and CIPET testing certificate from firms in Odisha.
The contractor must arrange necessary tools and plants for efficient execution of work at their own cost.
The contractor must abide by the C.P.W.D safety code rules.
The contractor must ensure materials meet ISI/CPRI specifications; otherwise, specifications will be made by the Executive Engineer.

Source: Original DTCNView source document

Contract conditions

20 items

The completion period for each project is 90 days from the date of issue of the work order.
The validity of the offer is 180 days from the date of opening of the Financial Bids.
The cost of the Stamp paper for the agreement will be borne by the Tenderer.

Show 17 more

Compensation for delay is 0.5% on the estimated cost for every week the work remains uncommenced or unfinished, up to a maximum of 10% of the estimated cost.
If the contractor fails to meet progress milestones (1/4th work in 1/4th time, 1/2 work in 1/2 time, 3/4th work in 3/4th time), compensation of 0.3% on the estimated cost per week of incomplete work will be levied, not exceeding 10% of the estimated cost.
All taxes, cess, royalties, income taxes, and surcharges (except GST) are to be borne by the bidder; GST will be paid extra.
Royalties for materials used will be recovered from the bill based on government-fixed rates.
Payment will be made after successful completion of work, testing, commissioning, handing over to the concerned Pani Panchayat, and completion of all formalities with TPNODL.
Any defect occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
No interest is chargeable for dues or additional dues.
The contractor must sign each page of the tender paper; otherwise, the tender will be rejected.
The contractor is responsible for compensating any damage to government or private property during pipeline work.
The contractor must not sublet the contract without written approval from the Executive Engineer.
No claim for idle labour/machinery/equipment will be entertained.
No compensation will be paid for damage due to natural calamities.
The Corporation reserves the right to increase or decrease quantities of work items; no compensation will be provided for this, except for time extension if necessary.
The work may be split and distributed among several contractors without compensation to the original contractor.
The contractor must abide by fair wages clauses and not pay less than the minimum wages fixed by the Government.
The contractor must submit a monthly return of labour employed.
The contractor must not employ child labour.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

57 priced items · ₹27.19 L (₹27,18,502)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply56%₹15.15 L
Earthwork & excavation25%₹6.67 L
Electrical11%₹3.04 L
Concrete & RCC4%₹1.11 L
Masonry3%₹88.8K
Reinforcement steel1%₹18.9K

Largest items

By amount

Cost, Supplying of ISI marked 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 for water supply as…Item 1.2 · 946 Mtr₹5.14 L
Construction and erection of 11 /0.4 KV , 25 KVA Double Pole mounted Substation with 5mtrx3mtrx1.5mtr height…Item 2.02 · 1 No₹4.06 L
Fitting and Fixing 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 Pipe including jointing the pi…Item 1.21 · 946 Mtr₹3.25 L
Construction of 3 phase 11 KV HT line as per REC standard confirming to IE Rules 1956 with 300 kg 9 M long PS…Item 2.01 · 0.4 Km.₹2.08 L
From 0 mtr. to 100th metersItem 3.03 · 90 Per mtr.₹1.90 L

Tender details

Tender reference: OLIC_02_26_27
Tender ID: 2026_OLIC_144327_60
District: Jajpur
Location: Jajpur Road
Tender type: Open Tender
Tender category: Works

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 755019

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI,Central Circle, Cuttack
Office
LI Division Jajpur Road
Inviting authority
Executive Engineer L.I.DIvision, Jajpur Road

All Orissa Lift Irrigation Corporation tenders in Jajpur →

Costs

Estimated value: ₹27,65,895; ₹27.66 lakh
EMD / bid security: ₹27,659; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (14)

SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference and EMD exemption
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, with specific calculation rules based on the 'Rounding Off of Percentage Less (ROPL)'.
APS is not required if ROPL is up to (-)10%.
APS calculation varies for ROPL below (-)10% to (-)20%, below (-)20% to (-)30%, and below (-)30% or more.
APS shall be treated as part of the performance security and is applicable to all forms of tender except Turnkey Tender.
APS shall be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days after receipt of Letter of Intimation, with a 1% ISD Value deposit.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
1% / 2% (as applicable) of the gross bill amount will be deducted towards income tax, plus surcharge and cess.
1% of the gross bill amount will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed65 requirements extracted22 documents identifiedExtracted from the official tender document

Eligibility

8 items

Reputed Contractors/Firms with valid PWD License of required class for Civil Works.
Contractors must have a registered HT License issued by ELBO.
Contractors must be registered in the State portal and possess a compatible digital signature certificate for online bidding.

Show 5 more

Contractors must have a Truck mounted Mud Rotary Rig for Drilling of TWs or a joint venture agreement with a rig owner.
Contractors registered under other State Govt. / M.E.s /Railways /CPWD in equivalent rank may participate, but successful bidders must register under the state PWD before signing the agreement.
In a joint venture, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
The P.A. holders of any SC/ST bidders should belong to the SC/ST category only.
Defaulter contractors are not allowed to participate.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Contractors with work experience of drilling works, having their own Rig, are to participate in a Joint Venture Agreement with the Civil Contractor in OLIC during the last 5 years.
Experience certificates should be obtained from an authority not less than the rank of an Executive Officer of the RIG holder.

Source: Original DTCNView source document

Financial

16 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference and EMD exemption (if they furnish an affidavit stating they have not been awarded a minimum of 3 works during the current financial year)
EMD is 1% of the Estimated Cost, to be deposited online.

Show 13 more

EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, with specific calculation rules based on the 'Rounding Off of Percentage Less (ROPL)'.
APS is not required if ROPL is up to (-)10%.
APS calculation varies for ROPL below (-)10% to (-)20%, below (-)20% to (-)30%, and below (-)30% or more.
APS shall be treated as part of the performance security and is applicable to all forms of tender except Turnkey Tender.
APS shall be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days after receipt of Letter of Intimation, with a 1% ISD Value deposit.
Non-entering into agreement shall lead to forfeiture of Earnest Money.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
1% / 2% (as applicable) of the gross bill amount will be deducted towards income tax, plus surcharge and cess.
1% of the gross bill amount will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

18 items

Possession of a Truck mounted Mud Rotary Rig for Drilling of TWs.
For * TW projects, Rig Owner’s Experience Certificates with RC Book, Fitness, Permit, Insurance, Pollution Certificates are required.
For ** TW packages, Rig RC Book, Fitness, Permit, Insurance, Pollution Certificates are required.

Show 15 more

Weightage may be given to contractors having their own plants and machinery (Rig & Ancillaries).
Contractor shall employ Engineers/Technical staff as per norms of the Govt. of Odisha.
The work involves erecting 11 K.V. H.T. line, L.T. line, and commissioning of 11/0.4 KV substations ranging from 25 KVA to 100 KVA.
Materials for 11 KV line: 55/80 mm2 A.A.A.C. conductor, span length 0.07 km (may vary).
Materials for L.T. line: A.B. conductor of 34 mm2 and AAA conductor of 34 mm2, span length 0.03 km (may vary).
Transformer test certificates issued by the manufacturer are required.
Transformer oil characteristics must meet specified standards (e.g., density, viscosity, flash point, breakdown voltage).
Lightening arrester technical particulars must meet REC Specification No. F-9 (e.g., type, rated voltage, discharge current).
Materials for cut points, guarding, and line D.P. for 11 KV overhead lines must adhere to specified quantities and types.
All materials supplied by the contractor should be procured from firms in Odisha and approved by the Engineer-in-charge.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
UPVC pipes must bear ISI mark and CIPET testing certificate from firms in Odisha.
The contractor must arrange necessary tools and plants for efficient execution of work at their own cost.
The contractor must abide by the C.P.W.D safety code rules.
The contractor must ensure materials meet ISI/CPRI specifications; otherwise, specifications will be made by the Executive Engineer.

Source: Original DTCNView source document

Contract conditions

20 items

The completion period for each project is 90 days from the date of issue of the work order.
The validity of the offer is 180 days from the date of opening of the Financial Bids.
The cost of the Stamp paper for the agreement will be borne by the Tenderer.

Show 17 more

Compensation for delay is 0.5% on the estimated cost for every week the work remains uncommenced or unfinished, up to a maximum of 10% of the estimated cost.
If the contractor fails to meet progress milestones (1/4th work in 1/4th time, 1/2 work in 1/2 time, 3/4th work in 3/4th time), compensation of 0.3% on the estimated cost per week of incomplete work will be levied, not exceeding 10% of the estimated cost.
All taxes, cess, royalties, income taxes, and surcharges (except GST) are to be borne by the bidder; GST will be paid extra.
Royalties for materials used will be recovered from the bill based on government-fixed rates.
Payment will be made after successful completion of work, testing, commissioning, handing over to the concerned Pani Panchayat, and completion of all formalities with TPNODL.
Any defect occurring within 18 months of commissioning must be rectified by the contractor within 7 days.
No interest is chargeable for dues or additional dues.
The contractor must sign each page of the tender paper; otherwise, the tender will be rejected.
The contractor is responsible for compensating any damage to government or private property during pipeline work.
The contractor must not sublet the contract without written approval from the Executive Engineer.
No claim for idle labour/machinery/equipment will be entertained.
No compensation will be paid for damage due to natural calamities.
The Corporation reserves the right to increase or decrease quantities of work items; no compensation will be provided for this, except for time extension if necessary.
The work may be split and distributed among several contractors without compensation to the original contractor.
The contractor must abide by fair wages clauses and not pay less than the minimum wages fixed by the Government.
The contractor must submit a monthly return of labour employed.
The contractor must not employ child labour.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹27,65,895

₹27.66 lakh

EMD / bid security

₹27,659

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (14)

SC/ST contractors with both Civil & Electrical Licenses are eligible for price preference and EMD exemption
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, with specific calculation rules based on the 'Rounding Off of Percentage Less (ROPL)'.
APS is not required if ROPL is up to (-)10%.
APS calculation varies for ROPL below (-)10% to (-)20%, below (-)20% to (-)30%, and below (-)30% or more.
APS shall be treated as part of the performance security and is applicable to all forms of tender except Turnkey Tender.
APS shall be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days after receipt of Letter of Intimation, with a 1% ISD Value deposit.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
1% / 2% (as applicable) of the gross bill amount will be deducted towards income tax, plus surcharge and cess.
1% of the gross bill amount will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

Source: Original DTCN

Frequently asked questions

PKG56

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

PKG56

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more