What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 04 Nov 2026, 05:00 PM. Bids are scheduled to open on 05 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹26.88 L (₹26,88,237).

How much EMD is required?

The EMD (bid security) is ₹26.9K (₹26,882). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Contractors/Firms must have a valid PWD License of required class for Civil Works; Bidders must possess a Truck mounted Mud Rotary Rig for Drilling of TWs.

What work experience is required?

As extracted from the DTCN: For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate; Contractors must have executed similar type of work in the last five years.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI,Central Circle, Cuttack, LI Division Jajpur Road; the tender inviting authority is the Executive Engineer L.I.DIvision, Jajpur Road.

What documents are required to submit a bid?

The DTCN lists 22 documents, including PWD License (Civil Works), HT License (Electrical), Rig Owner's Experience Certificates (for TW packages), Rig RC Book (for TW packages), Rig Fitness Certificate (for TW packages), Rig Permit (for TW packages), and 16 more.

OtherLive

Nasadipur_II TW

Jajpur Road, Jajpur Orissa Lift Irrigation CorporationLI Division Jajpur Road

Tender ID 2026_OLIC_144464_2Ref OLIC_03_26_27

Estimated value: ₹26.88 L
EMD: ₹26.9K; Exemption available
Tender fee: ₹7.1K
Work period: —

Closing soon

1 day left

04 Nov 2026, 05:00 PM

About this tender

Orissa Lift Irrigation Corporation has invited bids for “Nasadipur_II TW” in Jajpur Road, Jajpur district, Odisha. The estimated tender value is ₹26.88 lakh. Bids must be submitted by 04 Nov 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Needs review: Tender is open — only 1 day left
Done: BOQ available · 58 items
Done: DTCN analysed · 37 requirements extracted
Done: 22 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published28 Oct 2026, 12:00 PM
Document downloadUntil 04 Nov 2026
Submission deadline· 1 day left04 Nov 2026, 05:00 PM
Bid opening05 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed37 requirements extracted22 documents identifiedExtracted from the official tender document

This tender from the Odisha Lift Irrigation Corporation Ltd. invites bids for 16 packages of drilling, installation, and energization of Lift Irrigation Projects in Dharmasala Constituency, Jajpur District. The work is on a turnkey basis, including civil works, drilling of tube wells, erection of 11KV and LT lines, commissioning of electrical substations, and installation of pump sets. Estimated costs range from Rs. 24.69 Lakh to Rs. 27.38 Lakh per package, with a key requirement for contractors to possess a valid PWD license for civil works and a truck-mounted mud rotary rig for drilling.

Eligibility

8 items

Contractors/Firms must have a valid PWD License of required class for Civil Works.
Bidders must possess a Truck mounted Mud Rotary Rig for Drilling of TWs.
Contractors must have a registered HT License issued by ELBO.

Show 5 more

Contractors registered with other State Govt. / M.E.s / Railways / CPWD in equivalent rank may participate but must register under Odisha PWD before signing the agreement.
For Joint Ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
Defaulter contractors are not allowed to participate.
SC/ST contractors seeking price preference must have both Civil & Electrical Licenses and be individual registered contractors up to 'B' Class (no preference for Joint Ventures).
PA holders of SC/ST bidders must belong to SC/ST category.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Contractors must have executed similar type of work in the last five years.
For TW packages, experienced Rig holders must participate in a joint venture with the required class of contractor and submit an experience certificate from an authority not less than the rank of Executive Officer.

Source: Original DTCNView source document

Financial

10 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.

Show 7 more

EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained from the selected bidder on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the 'Rounding Off of Percentage Less' (ROPL) of the accepted bid price.
The APS is part of the performance security and is applicable to all forms of tender except Turnkey Tender.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing an ISD Value of 1% in specified instruments.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
1% of the gross bill amount will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

9 items

Bidders must have a Truck mounted Mud Rotary Rig for Drilling of TWs.
Contractors having their own plants and machineries (Rig & Ancillaries) may be given weightage.
Contractor shall employ Engineers/Technical staff as per norms of the Govt. of Odisha.

Show 6 more

All transformers shall be subjected to routine tests at the manufacturer's work as per IS-2026/1977 or its latest amendment.
Transformer oil must meet specified characteristics regarding appearance, density, viscosity, flash point, neutralization value, electric strength, etc.
Lightening arresters must be Metal oxide gapless distribution type and meet REC Specification No. F-9.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied by the contractor should conform to the latest ISI / CPRI specifications, or specifications made by the Executive Engineer.
Bricks should be well burnt, of good quality, approved by the site Engineer, and confirm to the minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

7 items

The completion period for each project is 90 days.
The offer validity period is 180 days from the date of opening of Financial Bids.
A penalty of ½% on the estimated cost per week will be charged for delays in commencement or completion, up to a maximum of 10% of the estimated cost.

Show 4 more

For works exceeding one month, contractors must complete 1/4th, 1/2, and 3/4th of the work by 1/4th, 1/2, and 3/4th of the total time, respectively, failing which a compensation of 1/3% on the estimated cost per week will be levied.
All taxes, cess, royalties, income tax, surcharges, etc., except GST, are to be borne by the bidder; GST will be paid extra.
The defect liability period is 18 months from the date of commissioning of the project, during which the contractor must rectify any defects within 7 days.
Payment will be made after completion of work, handing over of electric line and substation to TPNODL, and completion of all formalities with TPNODL.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

58 priced items · ₹26.41 L (₹26,40,844)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply49%₹12.89 L
Earthwork & excavation24%₹6.23 L
Electrical19%₹5.03 L
Concrete & RCC4%₹1.08 L
Masonry3%₹86.7K
Reinforcement steel1%₹18.0K

Largest items

By amount

Cost, Supplying of ISI marked 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 for water supply as…Item 1.2 · 758 Mtr₹4.12 L
Construction and erection of 11 /0.4 KV , 25 KVA Double Pole mounted Substation with 5mtrx3mtrx1.5mtr height…Item 2.02 · 1 No₹4.06 L
Construction of 3 phase 11 KV HT line as per REC standard confirming to IE Rules 1956 with 300 kg 9 M long PS…Item 2.01 · 0.7 Km.₹3.65 L
Fitting and Fixing 160 mm dia High Density Polythelene (HDPE) Pipes PE 80-PN 4 Pipe including jointing the pi…Item 1.21 · 758 Mtr₹2.64 L
From 0 mtr. to 100th metersItem 3.3 · 90 Per mtr.₹1.90 L

Tender details

Tender reference: OLIC_03_26_27
Tender ID: 2026_OLIC_144464_2
District: Jajpur
Location: Jajpur Road
Tender type: Open Tender
Tender category: Works

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 755019

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI,Central Circle, Cuttack
Office
LI Division Jajpur Road
Inviting authority
Executive Engineer L.I.DIvision, Jajpur Road

All Orissa Lift Irrigation Corporation tenders in Jajpur →

Costs

Estimated value: ₹26,88,237; ₹26.88 lakh
EMD / bid security: ₹26,882; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (9)

EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained from the selected bidder on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the 'Rounding Off of Percentage Less' (ROPL) of the accepted bid price.
The APS is part of the performance security and is applicable to all forms of tender except Turnkey Tender.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing an ISD Value of 1% in specified instruments.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
1% of the gross bill amount will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed37 requirements extracted22 documents identifiedExtracted from the official tender document

Eligibility

8 items

Contractors/Firms must have a valid PWD License of required class for Civil Works.
Bidders must possess a Truck mounted Mud Rotary Rig for Drilling of TWs.
Contractors must have a registered HT License issued by ELBO.

Show 5 more

Contractors registered with other State Govt. / M.E.s / Railways / CPWD in equivalent rank may participate but must register under Odisha PWD before signing the agreement.
For Joint Ventures, the Civil Contractor must be the 1st Party with more than 51% share and be the prime contractor.
Defaulter contractors are not allowed to participate.
SC/ST contractors seeking price preference must have both Civil & Electrical Licenses and be individual registered contractors up to 'B' Class (no preference for Joint Ventures).
PA holders of SC/ST bidders must belong to SC/ST category.

Source: Original DTCNView source document

Experience

3 items

For TW projects, bidders without their own rig must submit a joint venture agreement with a rig owner, executed in the court of a First Class Magistrate/Executive Magistrate.
Contractors must have executed similar type of work in the last five years.
For TW packages, experienced Rig holders must participate in a joint venture with the required class of contractor and submit an experience certificate from an authority not less than the rank of Executive Officer.

Source: Original DTCNView source document

Financial

10 items

The firm must possess liquid assets or credit facilities of not less than 20% of the amount put to tender.
EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.

Show 7 more

EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained from the selected bidder on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the 'Rounding Off of Percentage Less' (ROPL) of the accepted bid price.
The APS is part of the performance security and is applicable to all forms of tender except Turnkey Tender.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing an ISD Value of 1% in specified instruments.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
1% of the gross bill amount will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

9 items

Bidders must have a Truck mounted Mud Rotary Rig for Drilling of TWs.
Contractors having their own plants and machineries (Rig & Ancillaries) may be given weightage.
Contractor shall employ Engineers/Technical staff as per norms of the Govt. of Odisha.

Show 6 more

All transformers shall be subjected to routine tests at the manufacturer's work as per IS-2026/1977 or its latest amendment.
Transformer oil must meet specified characteristics regarding appearance, density, viscosity, flash point, neutralization value, electric strength, etc.
Lightening arresters must be Metal oxide gapless distribution type and meet REC Specification No. F-9.
UPVC Pipe, HDPE Pipe, and other EPM rate contract items must be procured from EPM registered firms of Govt. of Odisha with Pre & Post inspection Certificates from CIPET authority.
Materials supplied by the contractor should conform to the latest ISI / CPRI specifications, or specifications made by the Executive Engineer.
Bricks should be well burnt, of good quality, approved by the site Engineer, and confirm to the minimum strength as per National Building Code.

Source: Original DTCNView source document

Contract conditions

7 items

The completion period for each project is 90 days.
The offer validity period is 180 days from the date of opening of Financial Bids.
A penalty of ½% on the estimated cost per week will be charged for delays in commencement or completion, up to a maximum of 10% of the estimated cost.

Show 4 more

For works exceeding one month, contractors must complete 1/4th, 1/2, and 3/4th of the work by 1/4th, 1/2, and 3/4th of the total time, respectively, failing which a compensation of 1/3% on the estimated cost per week will be levied.
All taxes, cess, royalties, income tax, surcharges, etc., except GST, are to be borne by the bidder; GST will be paid extra.
The defect liability period is 18 months from the date of commissioning of the project, during which the contractor must rectify any defects within 7 days.
Payment will be made after completion of work, handing over of electric line and substation to TPNODL, and completion of all formalities with TPNODL.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹26,88,237

₹26.88 lakh

EMD / bid security

₹26,882

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 90 days

Security & deductions from the DTCN (9)

EMD is 1% of the Estimated Cost, to be deposited online.
EMD will be forfeited if a successful bidder fails to execute the agreement or furnish the required Performance Security within the specified time limit.
EMD will be forfeited if any submitted documents are found false/fabricated/bogus, leading to blacklisting.
Additional Performance Security (APS) will be obtained from the selected bidder on an incremental basis if the accepted bid price is lower than the Cost Put to Tender, calculated based on the 'Rounding Off of Percentage Less' (ROPL) of the accepted bid price.
The APS is part of the performance security and is applicable to all forms of tender except Turnkey Tender.
The successful tenderer must execute an agreement in P.W.D. F2 Contract form within 7 days of receiving the Letter of Intimation, depositing an ISD Value of 1% in specified instruments.
The security deposit is 2% of the quoted value of the work, with the balance made up by deducting 5% from each payment.
1% of the gross bill amount will be deducted towards labour cess.
Security deposit @ 5% of the bill will be deducted and refunded after 18 months from the date of handing over, subject to final bill payment.

Source: Original DTCN

Frequently asked questions

Nasadipur_II TW

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

Nasadipur_II TW

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more