What is the last date to bid for this tender?

Bids must be submitted on the Odisha eProcurement portal (tendersodisha.gov.in) by 31 Oct 2026, 05:00 PM. Bids are scheduled to open on 02 Nov 2026, 11:00 AM.

What is the estimated value of this tender?

The estimated tender value is ₹21.23 L (₹21,23,000).

How much EMD is required?

The EMD (bid security) is ₹21.2K (₹21,230). The portal lists EMD exemption as available for eligible bidders — check the DTCN for who qualifies.

Who can bid for this tender?

The DTCN states: Contractors must have a valid Civil license of requisite class ("B", "C", "D" as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD; Contractors must have a valid H.T. License issued by ELBO, with validity for at least 1 month from the tender opening date.

What work experience is required?

As extracted from the DTCN: For Tube Well projects, bidders/contractors who do not own a DTH/Mud rotary Rig must submit a joint venture agreement with Rig owners/Contractors having ownership, executed in the court of the First-Class Magistrate/Executive Magistrate; Contractors must provide an experience certificate/supporting documents for similar nature of work, demonstrating satisfactory completion (not less than 80% of original contract value) of at least one similar work of not less than 40% of the proposed contract value in the last 5 years.

What is the completion period?

The period of work is 180 days, and bids must remain valid for 365 days.

Which department issued this tender?

This tender was issued by Orissa Lift Irrigation Corporation, LI Southern Circle Berhampur, LI Division Berhampur; the tender inviting authority is the Executive Engineer, L.I. Division, Berhampur.

What documents are required to submit a bid?

The DTCN lists 10 documents, including Online/Over the counter generated Paper cost & EMD challan, Valid Civil License, Valid Electrical (H.T) License, Valid GSTIN certificate, Valid PAN, Valid joint venture agreement (Registered), and 4 more.

OtherClosed

Handighara-VIII T/W

OdishaOrissa Lift Irrigation CorporationLI Division Berhampur

Tender ID 2026_OLIC_143574_32Ref OLIC/BRAHMAPUR/02-2026-27

Estimated value: ₹21.23 L
EMD: ₹21.2K; Exemption available
Tender fee: ₹7.1K
Work period: 180 days

Bid submission

Closed

Closed on 31 Oct 2026, 05:00 PM

Bid submission for this tender has closed. Browse closed tenders in the archive →

About this tender

Orissa Lift Irrigation Corporation has invited bids for “Handighara-VIII T/W” in Handighara under Purusottampur Block, Odisha. The estimated tender value is ₹21.23 lakh and the completion period is 180 days. Bids must be submitted by 31 Oct 2026, 05:00 PM.

Bid readiness

Based on the tender, not your profile

Not available: Bid submission has closed
Done: BOQ available · 68 items
Done: DTCN analysed · 64 requirements extracted
Done: 10 required documents identified
Needs review: Experience requirement needs review
Needs review: Financial requirements need review

Review requirements

Important dates

All times IST, as published on the portal

Published21 Oct 2026, 11:00 AM
Document downloadUntil 31 Oct 2026
Submission deadline31 Oct 2026, 05:00 PM
Bid opening02 Nov 2026, 11:00 AM

Tender intelligence

Eligibility & bid requirements

DTCN analysed64 requirements extracted10 documents identifiedExtracted from the official tender document

The Odisha Lift Irrigation Corporation Ltd. (OLIC) invites bids for the installation and energization of 50 new Tube Well Lift Irrigation Projects across various blocks in Ganjam District. The estimated cost for each project ranges from Rs. 18.31 Lakhs to Rs. 30.15 Lakhs. Contractors registered with the State Government or equivalent central government bodies, holding valid Civil and HT Licenses, are eligible to bid. The work is to be completed within 90 days from the date of the work order.

Eligibility

8 items

Contractors must have a valid Civil license of requisite class ("B", "C", "D" as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD.
Contractors must have a valid H.T. License issued by ELBO, with validity for at least 1 month from the tender opening date.
If a contractor has only a Civil or Electrical License, they must form a joint venture with another contractor, and the joint venture agreement must be registered in any registration office/Executive Magistrate.

Show 5 more

The Joint Venture Agreement must be registered at the Sub-Register/District Registration Office as per the Registration Act 1908, with an agreement period of not less than 18 months.
Contractors must have a valid GST Registration certificate and PAN issued by the I.T. Department.
The ownership documents of the Rig owner, including RC Book, GST registration, PAN, Fitness certificate, Permit, and Pollution Certificate, must be submitted.
A drilling contractor/owner of a Rig and electrical contractors cannot make a joint venture agreement with more than one Civil contractor in a single package; such bids will be rejected.
Price preference and other benefits will be allowed as per OPWD code for Joint Venture Contractors if both civil and electrical contractors fall under the same reserved category.

Source: Original DTCNView source document

Experience

6 items

For Tube Well projects, bidders/contractors who do not own a DTH/Mud rotary Rig must submit a joint venture agreement with Rig owners/Contractors having ownership, executed in the court of the First-Class Magistrate/Executive Magistrate.
Contractors must provide an experience certificate/supporting documents for similar nature of work, demonstrating satisfactory completion (not less than 80% of original contract value) of at least one similar work of not less than 40% of the proposed contract value in the last 5 years.
A weightage of 10% per year will be given to the cost of satisfactorily completed works of previous years to bring them to the current price level.

Show 3 more

Bidders who have been awarded similar works in the past but shown unsatisfactory progress, or declared defaulter contractors, are not eligible.
In case of Tube Well Projects, Rig owners/Contractors having ownership of Mud Rotary Rig/DTH Rig must have a minimum of 3 years of experience in successful drilling works to be eligible for a joint venture agreement.
The drilling contractor's experience certificate must be issued by a competent authority not below the rank of Divisional Officer.

Source: Original DTCNView source document

Financial

10 items

EMD @ 1% must be deposited by the bidder in Online Mode through the e-portal.
If a bidder withdraws their bid or modifies terms before the validity period, the EMD/ISD deposited will be forfeited.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days from the date of issue of the letter of intent.

Show 7 more

Additional Performance Security (APS) will be calculated incrementally based on the Rounding Off of Percentage Less (ROPL) of the accepted bid price compared to the Cost Put to Tender.
APS is not required if ROPL is up to (-)10%.
If ROPL is below (-)10% but not below (-)20%, APS increases by 0.2% for every percentage below (-)10%.
If ROPL is below (-)20% but not below (-)30%, APS increases by 0.3% for every percentage below (-)20%, plus 2% of the accepted bid price.
If ROPL is below (-)30% or more, APS increases by 0.5% for every percentage below (-)30%, plus 5% of the accepted bid price.
APS will be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The security deposit amount will be refunded only after completion of the 18-month guarantee period to the satisfaction of the Executive Engineer.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

16 items

Price preference and other financial benefits will be allowed to SC/ST Contractors, Engineer Contractors, or Physically Handicapped Contractors having both Civil & Electrical Licenses in their name as per OPWD Code.
The contractor must supply all materials, equipment, tools, and plants, ensuring materials conform to relevant latest editions of BIS/REC specifications.
The contractor must furnish necessary certificates for material quality, and the Engineer-in-charge has the authority to test materials through a reputed laboratory at the contractor's cost.

Show 13 more

The contractor must submit copies of original purchase bills/vouchers for materials with the bill for payment.
The contractor shall procure required HDPE pipe from valid EPM rate contract holders within Odisha and arrange for pre and post-delivery inspection by CIPET, Odisha.
The contractor must arrange for inspection by the Electrical Inspector and obtain formal approval for energization of the sub-station upon completion of electrical works.
The contractor must ensure all construction works (Pump Chamber, Fixed foundation, Distribution Tank, ARV Tank, Butterfly Valve Tank, Supporting Pillar, HDPE Pipe Line, Road Crossing, Drilling of Bore) are executed as per enclosed specifications and Engineer-in-Charge's direction.
Electrical construction works, including 11 KV HT Line, Sub-Station (25 KVA/63 KVA/100 KVA), and 3 Phase 4/5 Wire LT Line, must be executed as per REC standard and specification.
The transformer to be installed must be tested by an approved authority before commissioning, and a successful test report must be enclosed with the bill of works.
The contractor must liaise with TPSODL, Electrical Division, Brahmapur for execution of Pani Panchayat agreements, shut down, connection, charging of S/S, and handing over.
The contractor must provide details of their firm, including articles of association/registration, list of personnel with qualifications, experience, and specialization, and list of tools and plants available.
The contractor must provide a list of works completed as per eligibility criteria in Form-F.
The contractor must ensure all materials used for civil works, such as HDPE pipe, G.I. pipe, pump, control panel starter, cable, PVC copper wire, electrical consumable materials, main switch, G.I. fittings, C.I. Foot Valve/NR Valve/Sluice Valve, C.I. Air Release Valve, and HDPE Fittings, conform to specified ISI standards and quality requirements.
The contractor must ensure bricks used are well burnt, of good quality, and confirm to minimum strength as per National Building Code.
The contractor must make arrangements for water supply for all works and proper curing of masonry works at their own cost.
The contractor must bear the cost of bailing out water from foundations if necessary.

Source: Original DTCNView source document

Contract conditions

24 items

The approximate estimated cost for each project ranges from Rs. 18.31 Lakhs to Rs. 30.15 Lakhs.
The period of completion is 90 days for all projects from the date of issue of the work order.
The bid will remain open for acceptance for a period of 365 days from the last date of receipt of bids.

Show 21 more

The successful lowest bidder must submit originals of all scanned documents within 5 days from the bid opening date for verification.
If more than one bidder is L1 (quoting less than or equal to estimated cost), the tender will be decided through a transparent lottery system.
Not more than 7 packages shall ordinarily be awarded to a single contractor; the authority reserves the right to reject excess packages.
The successful tenderer must execute agreements with the Executive Engineer, L.I. Division, Brahmapur within 7 days from the date of issue of the letter of intent.
The agreement should be on an approved PWD Form, incorporating all terms and conditions of this bid.
The contractor must quote the Percentage Rate excess or less up to two digits only after the decimal point.
The contractor must furnish a guarantee that all work items are free from defects for a period of not less than 18 months from the date of handing over the project.
During the guarantee period, the contractor must replace defective materials or rectify defects within 15 days as pointed out by the Engineer-in-Charge.
Payment to the contractor will be made on a "First & Final bill" basis after successful trial of the project and handing over to the concerned Pani Panchayat/TPSODL.
A completion certificate will be issued by the Engineer-in-Charge after successful trial, signed by Pani Panchayat office bearers, the contractor, and Assistant Engineer (Civil)/Assistant Executive Engineer (Civil).
Compensation for delay will be ½ percent on the estimated cost for every day the work remains uncompleted, not exceeding 10 percent of the estimated cost.
The contractor is liable to pay compensation of one-third percent on the estimated cost for every day the due quantity of work remains incomplete if progress milestones are not met.
The contractor shall bear all taxes including GST, Income Tax, Royalty, fair weather charges, and Labour cess.
The contractor shall not sublet the work without the written approval of the Executive Engineer.
The contractor must not employ any person below the age of eighteen years and must pay wages not less than those prescribed by the Government of Odisha.
The contractor is responsible for safe custody of materials at the site; OLIC will not be responsible for any loss or damage.
Unilateral stoppage of work without prior written permission will be considered a breach of contract.
The contractor must take precautions not to damage property and indemnify OLIC against claims for injuries or damages arising from negligence.
The contractor must provide necessary fencing and light to protect the public from accidents.
The contractor must arrange for M.V. Inspection and obtain a report from the Assistant Electrical Inspector; inspection fees are reimbursable by OLIC.
No payment will be made for partial completion of power supply work; a completion certificate for electrical wings will be issued only after full erection, inspection report, Pani Panchayat agreement, charging of Sub-Station, and handing over to TPSODL.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Bill of quantities

68 priced items · ₹20.86 L (₹20,86,122)

Download BOQ file

Major components

Share of BOQ amount, grouped by item description

Plumbing & water supply42%₹8.86 L
Electrical23%₹4.84 L
Earthwork & excavation21%₹4.32 L
Plaster, paint & finishing9%₹1.79 L
Concrete & RCC2%₹43.4K
Masonry2%₹37.0K

Largest items

By amount

Cost, Supplying of ISI marked High Density Polythelene (HDPE) Pipes for water supply as per IS 4984/2016 in t…Item 1.37 · 730 M₹3.96 L
Construction erection of 11/0.416 KV, 25 KVA (BIS level-II star 2) D.P mounted Sub-Station including transfor…Item 1.53 · 1 NO₹3.67 L
Fitting of 160 mm outer dia High Density Polythylene Pipes of specified material grade pressure rating by but…Item 1.14 · 730 M₹2.60 L
Construction of outlet at TankItem 1.17 · 20 NO₹1.78 L
Construction of 3 phase 3 wire 11 KV HT line as per REC standard confirming to RE Rules 1956 excluding 400 Kg…Item 1.52 · 0.34 KM₹1.73 L

Tender details

Tender reference: OLIC/BRAHMAPUR/02-2026-27
Tender ID: 2026_OLIC_143574_32
Location: Handighara under Purusottampur Block
Tender type: Open Tender
Tender category: Works
Period of work: 180 days

Show all 8 fields

Product category: Civil Works - Lift Irrigation Schemes
Pincode: 760006

Authority

State
Government of Odisha
Department
Orissa Lift Irrigation Corporation
Organisation
LI Southern Circle Berhampur
Office
LI Division Berhampur
Inviting authority
Executive Engineer, L.I. Division, Berhampur

Costs

Estimated value: ₹21,23,000; ₹21.23 lakh
EMD / bid security: ₹21,230; Exemption available for eligible bidders
Tender fee: ₹7,080; Cost of bid document

Bid validity: 365 days

Security & deductions from the DTCN (10)

EMD @ 1% must be deposited by the bidder in Online Mode through the e-portal.
If a bidder withdraws their bid or modifies terms before the validity period, the EMD/ISD deposited will be forfeited.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days from the date of issue of the letter of intent.
Additional Performance Security (APS) will be calculated incrementally based on the Rounding Off of Percentage Less (ROPL) of the accepted bid price compared to the Cost Put to Tender.
APS is not required if ROPL is up to (-)10%.
If ROPL is below (-)10% but not below (-)20%, APS increases by 0.2% for every percentage below (-)10%.
If ROPL is below (-)20% but not below (-)30%, APS increases by 0.3% for every percentage below (-)20%, plus 2% of the accepted bid price.
If ROPL is below (-)30% or more, APS increases by 0.5% for every percentage below (-)30%, plus 5% of the accepted bid price.
APS will be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The security deposit amount will be refunded only after completion of the 18-month guarantee period to the satisfaction of the Executive Engineer.

Source: Original DTCN

Frequently asked questions

Eligibility & bid requirements

DTCN analysed64 requirements extracted10 documents identifiedExtracted from the official tender document

Eligibility

8 items

Contractors must have a valid Civil license of requisite class ("B", "C", "D" as per tender) registered with State RWSS/PHED/Irrigation/Minor Irrigations/RW/PWD.
Contractors must have a valid H.T. License issued by ELBO, with validity for at least 1 month from the tender opening date.
If a contractor has only a Civil or Electrical License, they must form a joint venture with another contractor, and the joint venture agreement must be registered in any registration office/Executive Magistrate.

Show 5 more

The Joint Venture Agreement must be registered at the Sub-Register/District Registration Office as per the Registration Act 1908, with an agreement period of not less than 18 months.
Contractors must have a valid GST Registration certificate and PAN issued by the I.T. Department.
The ownership documents of the Rig owner, including RC Book, GST registration, PAN, Fitness certificate, Permit, and Pollution Certificate, must be submitted.
A drilling contractor/owner of a Rig and electrical contractors cannot make a joint venture agreement with more than one Civil contractor in a single package; such bids will be rejected.
Price preference and other benefits will be allowed as per OPWD code for Joint Venture Contractors if both civil and electrical contractors fall under the same reserved category.

Source: Original DTCNView source document

Experience

6 items

For Tube Well projects, bidders/contractors who do not own a DTH/Mud rotary Rig must submit a joint venture agreement with Rig owners/Contractors having ownership, executed in the court of the First-Class Magistrate/Executive Magistrate.
Contractors must provide an experience certificate/supporting documents for similar nature of work, demonstrating satisfactory completion (not less than 80% of original contract value) of at least one similar work of not less than 40% of the proposed contract value in the last 5 years.
A weightage of 10% per year will be given to the cost of satisfactorily completed works of previous years to bring them to the current price level.

Show 3 more

Bidders who have been awarded similar works in the past but shown unsatisfactory progress, or declared defaulter contractors, are not eligible.
In case of Tube Well Projects, Rig owners/Contractors having ownership of Mud Rotary Rig/DTH Rig must have a minimum of 3 years of experience in successful drilling works to be eligible for a joint venture agreement.
The drilling contractor's experience certificate must be issued by a competent authority not below the rank of Divisional Officer.

Source: Original DTCNView source document

Financial

10 items

EMD @ 1% must be deposited by the bidder in Online Mode through the e-portal.
If a bidder withdraws their bid or modifies terms before the validity period, the EMD/ISD deposited will be forfeited.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days from the date of issue of the letter of intent.

Show 7 more

Additional Performance Security (APS) will be calculated incrementally based on the Rounding Off of Percentage Less (ROPL) of the accepted bid price compared to the Cost Put to Tender.
APS is not required if ROPL is up to (-)10%.
If ROPL is below (-)10% but not below (-)20%, APS increases by 0.2% for every percentage below (-)10%.
If ROPL is below (-)20% but not below (-)30%, APS increases by 0.3% for every percentage below (-)20%, plus 2% of the accepted bid price.
If ROPL is below (-)30% or more, APS increases by 0.5% for every percentage below (-)30%, plus 5% of the accepted bid price.
APS will be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The security deposit amount will be refunded only after completion of the 18-month guarantee period to the satisfaction of the Executive Engineer.

The portal lists EMD exemption as available — bidders claiming it must meet the DTCN conditions and usually submit an affidavit.

Source: Original DTCNView source document

Technical

16 items

Price preference and other financial benefits will be allowed to SC/ST Contractors, Engineer Contractors, or Physically Handicapped Contractors having both Civil & Electrical Licenses in their name as per OPWD Code.
The contractor must supply all materials, equipment, tools, and plants, ensuring materials conform to relevant latest editions of BIS/REC specifications.
The contractor must furnish necessary certificates for material quality, and the Engineer-in-charge has the authority to test materials through a reputed laboratory at the contractor's cost.

Show 13 more

The contractor must submit copies of original purchase bills/vouchers for materials with the bill for payment.
The contractor shall procure required HDPE pipe from valid EPM rate contract holders within Odisha and arrange for pre and post-delivery inspection by CIPET, Odisha.
The contractor must arrange for inspection by the Electrical Inspector and obtain formal approval for energization of the sub-station upon completion of electrical works.
The contractor must ensure all construction works (Pump Chamber, Fixed foundation, Distribution Tank, ARV Tank, Butterfly Valve Tank, Supporting Pillar, HDPE Pipe Line, Road Crossing, Drilling of Bore) are executed as per enclosed specifications and Engineer-in-Charge's direction.
Electrical construction works, including 11 KV HT Line, Sub-Station (25 KVA/63 KVA/100 KVA), and 3 Phase 4/5 Wire LT Line, must be executed as per REC standard and specification.
The transformer to be installed must be tested by an approved authority before commissioning, and a successful test report must be enclosed with the bill of works.
The contractor must liaise with TPSODL, Electrical Division, Brahmapur for execution of Pani Panchayat agreements, shut down, connection, charging of S/S, and handing over.
The contractor must provide details of their firm, including articles of association/registration, list of personnel with qualifications, experience, and specialization, and list of tools and plants available.
The contractor must provide a list of works completed as per eligibility criteria in Form-F.
The contractor must ensure all materials used for civil works, such as HDPE pipe, G.I. pipe, pump, control panel starter, cable, PVC copper wire, electrical consumable materials, main switch, G.I. fittings, C.I. Foot Valve/NR Valve/Sluice Valve, C.I. Air Release Valve, and HDPE Fittings, conform to specified ISI standards and quality requirements.
The contractor must ensure bricks used are well burnt, of good quality, and confirm to minimum strength as per National Building Code.
The contractor must make arrangements for water supply for all works and proper curing of masonry works at their own cost.
The contractor must bear the cost of bailing out water from foundations if necessary.

Source: Original DTCNView source document

Contract conditions

24 items

The approximate estimated cost for each project ranges from Rs. 18.31 Lakhs to Rs. 30.15 Lakhs.
The period of completion is 90 days for all projects from the date of issue of the work order.
The bid will remain open for acceptance for a period of 365 days from the last date of receipt of bids.

Show 21 more

The successful lowest bidder must submit originals of all scanned documents within 5 days from the bid opening date for verification.
If more than one bidder is L1 (quoting less than or equal to estimated cost), the tender will be decided through a transparent lottery system.
Not more than 7 packages shall ordinarily be awarded to a single contractor; the authority reserves the right to reject excess packages.
The successful tenderer must execute agreements with the Executive Engineer, L.I. Division, Brahmapur within 7 days from the date of issue of the letter of intent.
The agreement should be on an approved PWD Form, incorporating all terms and conditions of this bid.
The contractor must quote the Percentage Rate excess or less up to two digits only after the decimal point.
The contractor must furnish a guarantee that all work items are free from defects for a period of not less than 18 months from the date of handing over the project.
During the guarantee period, the contractor must replace defective materials or rectify defects within 15 days as pointed out by the Engineer-in-Charge.
Payment to the contractor will be made on a "First & Final bill" basis after successful trial of the project and handing over to the concerned Pani Panchayat/TPSODL.
A completion certificate will be issued by the Engineer-in-Charge after successful trial, signed by Pani Panchayat office bearers, the contractor, and Assistant Engineer (Civil)/Assistant Executive Engineer (Civil).
Compensation for delay will be ½ percent on the estimated cost for every day the work remains uncompleted, not exceeding 10 percent of the estimated cost.
The contractor is liable to pay compensation of one-third percent on the estimated cost for every day the due quantity of work remains incomplete if progress milestones are not met.
The contractor shall bear all taxes including GST, Income Tax, Royalty, fair weather charges, and Labour cess.
The contractor shall not sublet the work without the written approval of the Executive Engineer.
The contractor must not employ any person below the age of eighteen years and must pay wages not less than those prescribed by the Government of Odisha.
The contractor is responsible for safe custody of materials at the site; OLIC will not be responsible for any loss or damage.
Unilateral stoppage of work without prior written permission will be considered a breach of contract.
The contractor must take precautions not to damage property and indemnify OLIC against claims for injuries or damages arising from negligence.
The contractor must provide necessary fencing and light to protect the public from accidents.
The contractor must arrange for M.V. Inspection and obtain a report from the Assistant Electrical Inspector; inspection fees are reimbursable by OLIC.
No payment will be made for partial completion of power supply work; a completion certificate for electrical wings will be issued only after full erection, inspection report, Pani Panchayat agreement, charging of Sub-Station, and handing over to TPSODL.

Source: Original DTCNView source document

Requirements are extracted automatically and grouped for reading. Always verify final requirements in the original tender document before submitting a bid.

Costs

Estimated value

₹21,23,000

₹21.23 lakh

EMD / bid security

₹21,230

Exemption available for eligible bidders

Tender fee

₹7,080

Cost of bid document

Bid validity: 365 days

Security & deductions from the DTCN (10)

EMD @ 1% must be deposited by the bidder in Online Mode through the e-portal.
If a bidder withdraws their bid or modifies terms before the validity period, the EMD/ISD deposited will be forfeited.
The successful tenderer must deposit 1% of the accepted tendered amount as Initial Security Deposit (ISD) within 7 days from the date of issue of the letter of intent.
Additional Performance Security (APS) will be calculated incrementally based on the Rounding Off of Percentage Less (ROPL) of the accepted bid price compared to the Cost Put to Tender.
APS is not required if ROPL is up to (-)10%.
If ROPL is below (-)10% but not below (-)20%, APS increases by 0.2% for every percentage below (-)10%.
If ROPL is below (-)20% but not below (-)30%, APS increases by 0.3% for every percentage below (-)20%, plus 2% of the accepted bid price.
If ROPL is below (-)30% or more, APS increases by 0.5% for every percentage below (-)30%, plus 5% of the accepted bid price.
APS will be refunded immediately on successful completion of the work within 7 days of issuance of Completion Certificate/Provisional Completion Certificate.
The security deposit amount will be refunded only after completion of the 18-month guarantee period to the satisfaction of the Executive Engineer.

Source: Original DTCN

Frequently asked questions

Handighara-VIII T/W

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

Handighara-VIII T/W

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Eligibility

Experience

Financial

Technical

Contract conditions

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

What is the completion period?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more

About this tender

Bid readiness

Important dates

Eligibility & bid requirements

Bill of quantities

Major components

Largest items

Tender documents

Documents required for submission

Tender details

Authority

Costs

Frequently asked questions

What is the last date to bid for this tender?

What is the estimated value of this tender?

How much EMD is required?

Who can bid for this tender?

What work experience is required?

What is the completion period?

Which department issued this tender?

What documents are required to submit a bid?

Similar tenders

Helpful guides

Explore more